Inactive Service-Disabled Veteran-Owned Small Business (SDVOSB) Set-Aside (FAR 19.14)

THIS IS A PRE-SOLICITATION NOTICE This is not a request for proposal. This is a request for Standard Form (SF) 330 Architect-Engineer Qualifications packages only. All information needed to submit SF ... THIS IS A PRE-SOLICITATION NOTICE This is not a request for proposal. This is a request for Standard Form (SF) 330 Architect-Engineer Qualifications packages only. All information needed to submit SF 330 documents is contained herein. No solicitation package, technical information, or bidder/plan holder list will be issued. The Government will not pay, nor reimburse any costs associated with responding to this request. The Government is under no obligation to award a contract as a result of this announcement. GENERAL INFORMATION Veterans Health Administration (VHA) Regional Procurement Office West (RPOW) Network Contracting Office 20 (NCO20) is seeking sources and intends to award a firm fixed price design contract for Architect-Engineering (A-E) services. The scope of this project is to include all design services needed to assess, inspect, and site verify the existing conditions and produce a design to build a secure pharmacy cache (AHEC) in building Project # 653-24-110 Correct AHEC Deficiencies at the Veterans Affairs Roseburg, Oregon Campus. The A-E Services contract that is anticipated to be awarded will be procured in accordance with the Selection of Architects and Engineers statute [formerly known as the Brooks Architect Engineer Act], Federal Acquisition Regulation (FAR) subpart 36.6 Architectural and Engineering Services, VA Acquisition Regulation (VAAR) 836.6, and VA Acquisition Manual (VAAM) M836.6 Architect-Engineer Services. In accordance with FAR 36.209, Construction Contracts with Architect-Engineer Firms, no contract for the construction of a project shall be awarded to the firm that designed the project or its subsidiaries or affiliates, except with the approval of the head of the agency or authorized representative. PROJECT INFORMATION This project is a 100% set-aside for Service-Disabled Veteran-Owned Small Business (SDVOSB) concerns. The NAICS code for this procurement is 541330 Engineering Services and the annual small business size standard is $25.5M. A full design team is required to complete this project. The VA expects to award the anticipated A-E contract in approximately late June to early July 2024. The estimated magnitude of construction projects is between $500,000 and $1,000,000. The anticipated period of performance for completion of design is 140 calendar days after notice to proceed (NTP). SUBMISSION REQUIREMENTS: The below information contains the instructions and format that must be followed for the submission of the SF 330 Statement of Qualifications: Submit one (1) SF 330 Statement of Qualifications to Contracting Specialist Fannie-Ann Riddle-Koroma at Fannie-Ann.Riddle-Koroma@va.gov and Contracting Officer Sandra Snediker at Sandra.Snediker@va.gov. This must include Parts I and II and any applicable attachments. The submission must include the SF 330, Architect-Engineer Qualifications form which is available online at: http://www.cfm.va.gov/contract/ae.asp or https://www.gsa.gov/system/files/SF330-21.pdf The SF 330 submission is due by Friday, 24 May 2024 at 1:00 PM Pacific. The SF 330 must be submitted in one email and have a file size no larger than 5 MB. No hard copies will be accepted. The subject line of the email must read: SF 330 Submission 36C26024R0011 Project 653-24-110 Correct AHEC Deficiencies. The SF 330 submission must not exceed a total of 50 pages. This includes title page, table of contents, and any other relevant information. Any pages submitted by an offeror that exceed the limit will not be considered during the evaluation. Each page must be in Arial size 12 font, single spaced. Part II of the SF 330 and any CPARs or PPQs will NOT count toward the page limitation. A PPQ obtained for another SF 330 submission may be submitted for this project. However, if significant portions of the project have been completed since the PPQ was filled out, a new PPQ should be submitted to accurately assess the project. Firms must include the following information in section B of the SF 330 submission: SAM Unique Entity Identifier Tax ID number Cage code Primary point of contact s email address and phone number All questions must be submitted to fannie-ann.riddle-koroma@va.gov with the subject line SF 330 Questions - 36C26024R0011 Project 653-24-110 Correct AHEC Deficiencies. The cutoff for question submission is Friday, 10 May 2024 at 12:00 PM Pacific. Questions will be answered through amendment to the notice posted to Contract Opportunities at SAM.gov. This procurement is a 100% set-aside for SDVOSB concerns. Offers received from other than SDVOSBs will not be considered. Offerors must be certified as SDVOSBs by the U.S. Small Business Administration (SBA) and visible in the Veteran Small Business Certification (VetCert) database (https://veterans.certify.sba.gov/) at the time of SF 330 submission, written response submission, and award. Failure to be certified in the VetCert database at these times will result in the offeror being deemed ineligible for award. All joint ventures must be SBA certified at the time of SF 330 submission, written response submission, and award and must submit agreements that comply with 13 CFR 128.402 prior to contract award. All prime firms must meet the NAICS code requirement specified in this notice. The Contracting Officer will verify the NAICS code in VetCert. Failure to meet the NAICS code requirement may result in the rejection of the SF 330 submission. SF 330 submissions received after the date and time specified will not be considered. Late proposal rules per FAR 15.208 will be followed for late submittals. Firms not providing the required information may not be evaluated. All information must be included in the SF 330 submission package. It is the offeror s responsibility to check the Contract Opportunities website at SAM.gov for any revisions to this announcement prior to submitting their SF 330. A-E SELECTION PROCESS Firms who timely submit SF 330s in response to this announcement, and in accordance with submission requirements, will be considered for evaluation. The selection will be made as follows: SF 330s will be evaluated in accordance with the primary selection criteria as stated in this notice. These evaluations will determine the most highly qualified firms for this particular requirement. In accordance with FAR 36.602-3(c), at least three of the most highly qualified firms will then be notified of the Government s intent to hold discussions. Firms that were not selected for discussions will be notified at this time. In accordance with FAR 36.607(b), any requested debriefings of successful and unsuccessful firms will be held after final selection has taken place and will be conducted, to the extent practicable, in accordance with 15.503, 15.506(b) through (f), and 15.507(c). Note that 15.506(d)(2) through (d)(5) do not apply to architect-engineer contracts. Discussions will be held with top three firms in the form of written responses. The firms invited to participate in discussions will be notified by Contract Specialist or Contracting Officer by email with detailed instructions that will include questions or topics to address. Following the completion of discussions, the firms will be evaluated and ranked based on the primary and (if necessary) secondary selection criteria. The final evaluation and ranking will consider the SF 330 submission for each firm, as well as additional information obtained via discussions. The highest rated firm will be selected to receive the solicitation and engage in negotiations. The solicitation will be issued to the highest rated firm as a Request for Fee Proposal (RFP). All SOW attachments and site-specific documentation will be provided to the highest rated firm with the RFP. A site visit may be authorized during the negotiation process. An award will then be made as long as the negotiation of rates and hours leads to a fair, balanced, and reasonable determination of the final contract price. If negotiations with the highest rated firm are unsuccessful, the firm will be notified that negotiations have been terminated. Negotiations will then be initiated with the next highest rated firm, and so on until award can be made or this announcement is cancelled. PRIMARY SELECTION CRITERIA: Firms responding to this notice will be evaluated and ranked using the primary and secondary selection criteria listed below. The factors are listed in descending order of importance. The evaluation will consider how each factor is addressed and how it is formatted to coincide with the selection criteria. Selection Criteria 1, Professional Qualifications (Sections C through E): The evaluation will consider the professional qualification necessary for satisfactory performance of required service. The evaluation shall consider the specific experience (minimum of five years) and qualifications (i.e., education, training, registration, certifications, overall relevant experience, and longevity with the firm as full-time employees) of personnel proposed for assignment to the project, and their record of working together as a team when evaluating professional qualifications. The lead designer in each discipline must be registered but does not have to be registered in the particular state where the project is located. The A-E shall demonstrate they are able to sign and stamp each drawing by individuals licensed in any state in the United States for the key positions listed below. Provide Professional License numbers and/or proof of Licensure. A resume for each of these key positions must be provided via Section E of the SF 330. Key positions and disciplines required for this project may include among others: Architect CADD Technician Cost Estimator Electrical Engineer Fire Protection Engineer Mechanical Engineer Plumbing Engineer Project Manager Quality Assurance Registered Communications Distribution Designer (RCDD) Structural Engineer Offer must include the following statement of SDVOSB compliance on the cover page when submitting the personnel proposed to perform the work under this requirement: I [signatory authority] ___________________, [company or Joint Venture] __________________, certify that the SDVOSB prime contractor will not pay more than 50% of the amount paid by the government to the prime for contract performance to firms that are not certified SDVOSBs by the Small Business Association s Veteran Small Business Certification (VetCert) in compliance of VA Acquisition Regulation (VAAR) 852.219-75. The information provided in sections C through E of the SF 330 will be used to evaluate this evaluation factor. Do not include this information in section H, unless it is pertinent to support the information listed in the other sections. Selection Criteria 2, Specialized Experience and Technical Competence (sections F, G, and H): The evaluation will consider specialized experience and technical competence in design period services for correcting AHEC deficiencies by remodeling the existing AHEC space. Provide information for example projects which best illustrate the proposed team s experience and competencies for this contract. Submissions shall include information regarding experience and competence in the following areas: Active and occupied medical facility building remodeling. Repair existing conditions and issues in the renovation Provide architectural, electrical, mechanical, plumbing, HVAC, fire protection, communication. Phasing of renovation to minimize disruption to hospital operations: must remain operational throughout construction. Other specialized experience includes experience in critical path scheduling, fire protection, seismic design, construction infection control protocols, energy conservation, transition, pollution prevention, waste reduction, use of recovered materials, and sustainable design practices. Submissions shall include the following information for example projects: Project title, location and detailed narrative describing the scope of services provided including the type of work performed by the offeror and its role in the project i.e., prime contract, Teaming Partner, or subcontractor Project Owner, owner s point of contact including telephone number and email address. Services & Deliverables provided under the contract or task order number Period of Performance, including start and completion dates Total dollar value of the project Contract number associated with the project. Submissions shall include at least three (3) but no more than five (5) recent and relevant, Government and private experience, example projects, similar in size, scope, construction features and complexity, which clearly illustrate experience and competencies listed above and in other portions of this solicitation. Recent is defined as services provided in the five (5) years prior to the closing date of this solicitation. Relevant is defined as projects, within the United States, its territories, or possessions, requiring tasks identified in this solicitation. Similar complexity is considered projects of an operational, construction, or design likeness to the work covered in this solicitation. Three (3) of the five (5) example projects must have construction completed or construction substantially (50%+) complete. Submit example project information in Section F of the SF 330. Section G of the SF 330 will be used to evaluate the prior experience of the prime firm and any key subcontractors working together on the provided example projects. The evaluation will also consider narratives addressing the following topics for the Offeror, and key consultants, in Section H of the SF 330: The management s approach The coordination of disciplines and subcontractors Quality control procedures, and Familiarity with VA Design Guides/Manuals, Master Specifications, and other applicable standards. The narratives should clearly illustrate how each of the topics were addressed. Re-stating or reiterating this list or the Scope of Work in Section H will not be sufficient. Narratives submitted in Section H of the 330, shall not exceed one (1) page in length for the Offeror and each key consultant. The narrative submissions shall not exceed ten (10) pages total for this criterion. Selection Criteria 3, Capacity (Section H) The evaluation will consider the team s plan and the evaluation will consider the firm s ability to meet the schedule of the overall project, as well as the available capacity of key disciplines to perform the work in the required time. Provide the available capacity of key disciplines by providing current project workload, inclusive of all projects awarded during the previous 12 months and the full potential value of any current indefinite delivery contracts. Offeror shall clearly state their available capacity presenting workload percentages for the key disciplines and/or team members. Also, the offeror must provide the completion percentages and expected completion date for projects awarded in the previous 12 months. The information for this factor shall be provided in Section H of the SF 330. Please ensure the capacity applies toward the team/personnel provided in the SF 330. Selection Criteria 4, Past performance (section H) The evaluation will consider the firm s past performance on contracts with Government agencies and private industry in terms of cost control, quality of work, and compliance with performance schedules. Past performance will be evaluated for all projects provided in Section F. The Contractor Performance Assessment Rating System (CPARS) database will be reviewed to evaluate the projects that have a CPARS entry. CPARS are not required to be submitted with the SF330 submission. The contract number for the project must be submitted with each project in Section F so CPARS can be reviewed in the database. For any project that does NOT have CPARS data available, a Past Performance Questionnaire (PPQ) is required to be submitted with the SF 330. The PPQ should be rated and signed by the evaluator. In the event that a firm does not receive a requested complete PPQ from an evaluator prior to the time for submission, the firm shall submit the partially completed PPQ with Section 1 and the Evaluator Information in Section 2 completed. Ensure a POC is listed with the project title/contract number. The VA will make reasonable attempts to contact the POC upon submission for PPQ completion. Evaluations may also include additional performance related from the firm, customer inquiries, Government databases, publicly available sources, and additional projects in CPARS. The Government reserves the right to contact any POC listed on a CPARS report or PPQ. Failure to provide requested data, accessible points of contact, or valid phone numbers may result in a firm being considered less qualified. All projects provided in the SF 330 must be completed by the office/branch/individual team member performing the work under this contract. The information for this factor shall be provided in Section H of the SF 330. For PPQs, please utilize the attached PPQ document only. Completed PPQs should be incorporated into the SF 330 directly. PPQs should not be submitted separately to NCO20 directly. Any PPQs will not be counted towards the page limitations for this submission. However, any narratives provided for past performance in Section H shall not exceed two (2) pages in length and will be counted toward the total submission page limit. Selection Criteria 5, Knowledge of the locality (Section H), The evaluation will consider the knowledge of the locality, including specific knowledge of local conditions or project site features, such as geological features, climatic conditions, working with and local construction methods or local laws and regulations of the area of Roseburg, OR. The information for this factor shall be provided in Section H of the SF 330. Note that the intent of this factor is to showcase a firm s understanding of the project site and locality, and NOT where the firm is located, how far away the firm/branch office is from the site, and how they would travel to the site. Information related to the firm s location shall be provided in Section H under Secondary Selection Criterion Factor 1, Geographic Location. See below. Selection Criteria 6, Experience in Construction Period Services, (Section H) The evaluation will consider experience in Construction Period Services (CPS) necessary for performance of this contract. Submissions shall provide information which clearly illustrates CPS experience in the following: Solicitation support services Professional field inspections during the construction period, both scheduled and emergent Coordination with commissioning requirements/commissioning services Review of construction submittals for design conformance, variance, and applicable code/standard compliance Support in answering requests for information (RFI) during the construction period Support of construction contract changes to include drafting statements of work and cost estimates Maintaining a comprehensive submittal log inclusive of material data, shop drawings, certifications, etc. Providing timely and complete responses to requests for information Providing supporting documentation (statements of work, cost estimates, technical reports, etc.) for construction modifications Providing record drawing documentation Process for correcting design errors/omissions identified during construction Attendance at pre-bid, post-award, and commissioning kick off construction project conferences Providing minutes of weekly construction meetings throughout the duration of construction Site visits during construction both scheduled and emergent Ensuring compliance with the design drawings and specifications Preparation of site visit reports Generation of punch-list reports Review of construction project modifications for cost and technical acceptability Attendance and participation during the final acceptance inspection Preparation of record drawings of the completed construction project based on the construction contactor s as-built drawings Maintenance of RFI logs Attendance at weekly conference calls Providing minutes of meetings between the AE, VA, and contractors Pre-final inspection site visits Production of as-built documentation The information for this factor shall be provided in Section H of the SF 330.