Inactive Total Small Business Set-Aside (FAR 19.5)

•(i) This is a combined synopsis/solicitation for commercial items, prepared in accordance with the format in subpart 12.6 of the FAR and as supplemented with additional information included in this n... •(i) This is a combined synopsis/solicitation for commercial items, prepared in accordance with the format in subpart 12.6 of the FAR and as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a separate written solicitation will not be issued. •(ii) Solicitation number 70Z04019Q61122Y00 applies and is used as a Request For Quote RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-87, effective, 7 March 2016. •(iii) It is anticipated that a competitive price purchase order shall be awarded as a result of this synopsis/solicitation. All responsible sources may submit a quotation, which if timely received, shall be considered by this agency. •(iv) The U.S. Coast Guard, Surface Forces Logistics Center (SFLC) intends to award a Firm Fixed Price Purchase Order. •(v) The United States Coast Guard Surface Forces Logistics Center has a requirement for the following items: ITEM 1: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 26EH, TYPE H, 6 1/4" X 22", FLANGED WITH DRILLED HOLES, 13.5 KW, 440V, 3 PH. IAW MIL-H-22594 Part Number: M-22594-26EH TYPE H TFZ-26H NSN: 4520 01-LG1-0431 QTY: 01 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 2: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 25EH, TYPE L, 6-1/4" X 14" HOUSING, 2.9 KW, 440V, 3 PH IN ACCORDANCE WITH MIL-PRF-22594 OR MIL-H- 22594A. Part Number: 25 EH TYPE H TFZ-25L M-22594-25L NSN: 4520 01-LG0-8505 QTY: 04 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 3: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 29EH, TYPE H, 12-1/4" X 30" HOUSING, 36.2 KW, 440V, 3 PH, IN ACCORDANCE WITH MIL-H 22594A. Part Number: EH29H TFZ-29H M-22594-29EH TYPE H NSN: 4520 01-LG0-9882 QTY: 01 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 4: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 23EH, TYPE M, 3-1/4" X 14" HOUSING, 3.0 KW, 440V, 3 PH, IN ACCORDANCE WITH MIL-PRF-22594. WIDTH 20 INCHES, DEPTH 6 INCHES, HEIGHT 6.250 INCHES. INCLOSURE MATERIAL: STEEL, CORROSION RESISTING. Part Number: M-22594--23M NSN: 4520 01-191-3973 QTY: 06 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 5: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 20EH, TYPE H, 3-1/4" X 6" HOUSING, 1.0 KW, 115V, 3 PH IN ACCORDANCE WITH MILPRF-22594. Part Number: M-22594-20EH VDH-20H NSN: 4520 01-203-1101 QTY: 05 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 6: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 21EH, TYPE H, 3-1/4" X 6" HOUSING, 1.9 KW, 115V, 3 PH IN ACCORDANCE WITH MIL-PRF-22594 OR MIL-H-22594A. Part Number: EH21H M22594-21H TFZ-21H NSN: 4520 01-LG0-8490 QTY: 03 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ ITEM 7: HEATER, DUCT, NAVY STD, ELECTRIC, SIZE 22EH, TYPE M, 3-1/4" X 9" HOUSING, 1.93 KW, 440V, 3 PH IN ACCORDANCE WITH MIL-PRF-22594 OR MIL-H-22594A Part Number: EH22M M-22594-22M TFZ-22M NSN: 4520 01-LG0-8491 QTY: 02 EA UNIT PRICE: ________________ TOTAL: ___________________ REQUIRED DELIVERY DATE: 10/01/19 PROMISED DELIVERY DATE: ______________________ **FAILURE TO COMPLY WITH ALL PACKAGING AND MARKING REQUIREMENTS WILL RESULT IN MATERIAL BEING RETURNED, AT VENDORS EXPENSE, FOR CORRECTION. ** QUESTIONS PERTAINING TO THIS RFQ SHOULD BE DIRECTED TO: Elizabeth Garcia at elizabeth.j.garcia@uscg.mil. •(vi) PLACE OF DELIVERY: U.S. Coast Guard, Surface Forces Logistics Center, 2401 Hawkins Point Road, Bldg. 88 Receiving Rm., Baltimore, MD 21226. All deliveries are to be made Monday through Friday between the hours of 7:00 AM and 1:00 PM EST. PREPARATION FOR DELIVERY: All material shipped to the U.S. Coast Guard, Surface Forces Logistics Center, Bldg. 88, Receiving Room, and 2401 Hawkins Point Road, Baltimore, MD. 21226, on this purchase order, must be accompanied by an itemized packing list securely attached to the outside of the package. All packing lists shall cite the Purchase Order Number with the package in such a manner as to provide identification. Material shall be packed for shipment in such manner as to afford adequate protection to the item against corrosion, deterioration, and physical damage during shipment to Surface Forces Logistics Center locations. Package shall all provide adequate protection for warehouse storage and multiple shipments. All packages shall have the Purchase Order Number, Stock number (if applicable) and Vendor name and Part Number clearly marked on the exterior of the package. All deliveries are to be made Monday through Friday between the hours of 7:00 A.M. and 1:00 P.M. GOVERNMENT ACCEPTANCE: Acceptance will be made at destination by a Government representative. Acceptance will be contingent upon the representative's verification of no damage in transit, correctness and completeness of order. FAR 52.212-1 Instructions to Offeror-Commercial Items (OCT 2015). Parties responding to this solicitation may submit their offer in accordance with their standard commercial practices to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or email. As a minimum, offers must show: (1) The solicitation number (2) The time specified in the solicitation for receipt of offers; (3) The name, address, and telephone number of the Offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (5) Terms of any express warranty; (6) Price. Delivery information and any discount terms; (7) "Remit to" address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the Offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and (11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. (12) Dun & Bradstreet number. •(vii) FAR 52.212-2 Evaluation-Commercial Items (OCT 2014). - This is a commercial services acquisition. The evaluation and award procedures in FAR 13.106 apply. The following evaluation factors shall be considered: The Government will award a purchase order resulting from this solicitation to the responsible Offeror whose offer conforming to the solicitation will be most advantageous to the Government, price, delivery date and other factors considered. The following factors shall be used to evaluate offers: The Government will evaluate offers based on delivery date and lowest technically acceptable price. •(viii) FAR 52.212-3 Offeror Representations and Certifications-Commercial Items (MAR 2016) - An Offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certificates electronically via http://www.acquisition.gov . If an Offeror has not completed the annual representations and certifications electronically at the System for Award Management (SAM) website (www.sam.gov), the Offeror shall complete only paragraphs (c) through (o) of this provision. •(ix) FAR 52.212-4 Contract Terms and Conditions-Commercial Items (May 2015) applies to this acquisition. The following addendum applies: Address for submission of invoices is U.S. Coast Guard, P.O. Box 4122, Chesapeake, VA 23327-4122, Phone 757-523-6940 or Email address for submission of invoices is FIN-SMB-YARDTEAM@USCG.MIL . •(x) 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders -Commercial Items (MAR 2016) •(xi) FAR 52.213-4 Terms and Conditions - Simplified Acquisitions (Other Than Commercial Item). •(xii) The Contractor shall comply with the FAR clauses which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at http://farsite.hill.af.mil/. (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015). (3) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). __ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)). __ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) __ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note). __ (5) [Reserved]. __ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). __ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). __ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). __ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). __ (10) [Reserved]. __ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). __ (ii) Alternate I (Nov 2011) of 52.219-3. __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). __ (ii) Alternate I (Jan 2011) of 52.219-4. __ (13) [Reserved] X__ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644). __ (ii) Alternate I (Nov 2011). __ (iii) Alternate II (Nov 2011). __ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). __ (ii) Alternate I (Oct 1995) of 52.219-7. __ (iii) Alternate II (Mar 2004) of 52.219-7. __ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). __ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)). __ (ii) Alternate I (Nov 2016) of 52.219-9. __ (iii) Alternate II (Nov 2016) of 52.219-9. __ (iv) Alternate III (Nov 2016) of 52.219-9. __ (v) Alternate IV (Nov 2016) of 52.219-9. __ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). __ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). __ (20) 52.219-16, Liquidated Damages. Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). __ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f). _X_ (22) 52.219-28, Post Award Small Business Program Representation (Jul 2013) (15 U.S.C. 632(a)(2)). __ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). __ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). _X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (26) 52.222-19, Child Labor. Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). _X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X_ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). __ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212). __ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). __ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). __ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X_ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). __ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). __ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) __ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693). __ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). __ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Oct 2015) of 52.223-13. __ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-14. __ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). __ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-16. _X_ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513). __ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). __ (44) 52.223-21, Foams (Jun 2016) (E.O. 13693). __ (45)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a). __ (ii) Alternate I (JAN 2017) of 52.224-3. _X_ (46) 52.225-1, Buy American.Supplies (May 2014) (41 U.S.C. chapter 83). __ (47)(i) 52.225-3, Buy American.Free Trade Agreements.Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. __ (ii) Alternate I (May 2014) of 52.225-3. __ (iii) Alternate II (May 2014) of 52.225-3. __ (iv) Alternate III (May 2014) of 52.225-3. __ (48) 52.225-4, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X_ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). __ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). __ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). __ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). __ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). __ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _X_ (55) 52.232-33, Payment by Electronic Funds Transfer.System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (56) 52.232-34, Payment by Electronic Funds Transfer.Other than System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). __ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). __ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017)(15 U.S.C. 637(d)(12)). __ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). __ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). __ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). __ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards.Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment. Requirements (May 2014) (41 U.S.C. chapter 67). __ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services. Requirements (May 2014) (41 U.S.C. chapter 67). __ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). __ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). __ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). __ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records. Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause. (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17. (v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015) (vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246). (vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xi) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). (xii) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627). __(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627). (xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). (xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). (xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989). (xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xvii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706). (xviii)(A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (B) Alternate I (Jan 2017) of 52.224-3. (xix) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xx) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of clause) 52.246-2 - Inspection of Supplies -- Fixed-Price (Aug. 1996) (a) Definition. "Supplies," as used in this clause, includes but is not limited to raw materials, components, intermediate assemblies, end products, and lots of supplies. (b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering supplies under this contract and shall tender to the Government for acceptance only supplies that have been inspected in accordance with the inspection system and have been found by the Contractor to be in conformity with contract requirements. As part of the system, the Contractor shall prepare records evidencing all inspections made under the system and the outcome. These records shall be kept complete and made available to the Government during contract performance and for as long afterwards as the contract requires. The Government may perform reviews and evaluations as reasonably necessary to ascertain compliance with this paragraph. These reviews and evaluations shall be conducted in a manner that will not unduly delay the contract work. The right of review, whether exercised or not, does not relieve the Contractor of the obligations under the contract. (c) The Government has the right to inspect and test all supplies called for by the contract, to the extent practicable, at all places and times, including the period of manufacture, and in any event before acceptance. The Government shall perform inspections and tests in a manner that will not unduly delay the work. The Government assumes no contractual obligation to perform any inspection and test for the benefit of the Contractor unless specifically set forth elsewhere in this contract. (d) If the Government performs inspection or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. Except as otherwise provided in the contract, the Government shall bear the expense of Government inspections or tests made at other than the Contractor's or subcontractor's premises; provided, that in case of rejection, the Government shall not be liable for any reduction in the value of inspection or test samples. (e) (1) When supplies are not ready at the time specified by the Contractor for inspection or test, the Contracting Officer may charge to the Contractor the additional cost of inspection or test. (2) The Contracting Officer may also charge the Contractor for any additional cost of inspection or test when prior rejection makes reinspection or retest necessary. (f) The Government has the right either to reject or to require correction of nonconforming supplies. Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with contract requirements. The Government may reject nonconforming supplies with or without disposition instructions. (g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice, by and at the expense of the Contractor. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and, when required, shall disclose the corrective action taken. (h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1) by contract or otherwise, remove, replace, or correct the supplies and charge the cost to the Contractor or (2) terminate the contract for default. Unless the Contractor corrects or replaces the supplies within the delivery schedule, the Contracting Officer may require their delivery and make an equitable price reduction. Failure to agree to a price reduction shall be a dispute. (i) (1) If this contract provides for the performance of Government quality assurance at source, and if requested by the Government, the Contractor shall furnish advance notification of the time -- (i) When Contractor inspection or tests will be performed in accordance with the terms and conditions of the contract; and (ii) When the supplies will be ready for Government inspection. (2) The Government's request shall specify the period and method of the advance notification and the Government representative to whom it shall be furnished. Requests shall not require more than 2 workdays of advance notification if the Government representative is in residence in the Contractor's plant, nor more than 7 workdays in other instances. (j) The Government shall accept or reject supplies as promptly as practicable after delivery, unless otherwise provided in the contract. Government failure to inspect and accept or reject the supplies shall not relieve the Contractor from responsibility, nor impose liability on the Government, for nonconforming supplies. (k) Inspections and tests by the Government do not relieve the Contractor of responsibility for defects or other failures to meet contract requirements discovered before acceptance. Acceptance shall be conclusive, except for latent defects, fraud, gross mistakes amounting to fraud, or as otherwise provided in the contract. (l) If acceptance is not conclusive for any of the reasons in paragraph (k) hereof, the Government, in addition to any other rights and remedies provided by law, or under other provisions of this contract, shall have the right to require the Contractor (1) at no increase in contract price, to correct or replace the defective or nonconforming supplies at the original point of delivery or at the Contractor's plant at the Contracting Officer's election, and in accordance with a reasonable delivery schedule as may be agreed upon between the Contractor and the Contracting Officer; provided, that the Contracting Officer may require a reduction in contract price if the Contractor fails to meet such delivery schedule, or (2) within a reasonable time after receipt by the Contractor of notice of defects or nonconformance, to repay such portion of the contract as is equitable under the circumstances if the Contracting Officer elects not to require correction or replacement. When supplies are returned to the Contractor, the Contractor shall bear the transportation cost from the original point of delivery to the Contractor's plant and return to the original point when that point is not the Contractor's plant. If the Contractor fails to perform or act as required in (1) or (2) above and does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure, the Government shall have the right by contract or otherwise to replace o...