Inactive Total Small Business Set-Aside (FAR 19.5)

**Proposals shall be sent via email in PDF format to the Contracting Officer at thupten.tsering@ihs.gov by the due date and time** ** See amendment 1 effective 8/15/2024 ** ** See amendment 2 effectiv... **Proposals shall be sent via email in PDF format to the Contracting Officer at thupten.tsering@ihs.gov by the due date and time** ** See amendment 1 effective 8/15/2024 ** ** See amendment 2 effective 8/26/2024 ** See attached SOLICITATION NOTICE for solicitation number 75H70123R00053 for a construction project for the Indian Health Service (IHS). The purpose of this project is the replacement French Doors throughout the quarters of the Cheyenne River Health Center quarters located in Eagle Butte, SD. Installation shall include surrounding frame work and painting as needed. in accordance with the specifications, drawings, and other documents provided under this solicitation. This project will be procured as a 100% Small Business set-aside solicitation under North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Eagle Butte, SD. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 365 calendar days after issuance of a Notice to Proceed. CONSTRUCTION MAGNITUDE: In accordance with FAR 36.204, the magnitude of this construction project is anticipated to be between $500,000.00 and $1,000,000.00 SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.

Inactive Total Small Business Set-Aside (FAR 19.5)

This is a PRESOLICITATION NOTICE for the upcoming Solicitation 75H70124R00053 Cheyenne River Quarters French Door Replacement, located in Eagle Butte, SD. These construction services will be in suppor... This is a PRESOLICITATION NOTICE for the upcoming Solicitation 75H70124R00053 Cheyenne River Quarters French Door Replacement, located in Eagle Butte, SD. These construction services will be in support of the Indian Health Service (IHS) prepared in accordance with FAR Part 36. The Government anticipates releasing the solicitation on or about August 10, 2024 and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://sam.gov under Contract Opportunities. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://sam.gov. SCOPE OF WORK: The purpose of this project is for the replacement of French Doors for 113 units at the Cheyenne River Health Center. Work shall include framing, repair of drywall, trim, and paint. LOCATION OF PROJECT: All work shall be performed at the Cheyenne River Health Center at 24276 Airport Rd, Eagle Butte, SD 57625. TERO: TERO fees do apply. (More information will be released in solicitation). Contact the TERO office at (605) 964-8376 for an explanation of tribal requirements. CONSTRUCTION DURATION: Period of Performance is 365 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000.00 and $1 million in accordance with FAR 36.204. SITE VISIT: Details regarding the Site Visit will be included in the solicitation. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. CONTRACT TYPE: The Indian Health Service intends to award a single Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable (LPTA) evaluation criteria. This project will be solicited as unrestricted, full and open competition under North American Industry Classification System (NAICS) code 236220 - Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Large Businesses will be required to submit a Small Business Subcontracting Plan upon award of contract. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last five (5) years is less than $19 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM. It is the responsibility of the contractor to check https://sam.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the initial notice including any subsequent amendments. No additional information is available other than what is noted herein. Firms are instructed not to call requesting more information.

Inactive

Cheyenne River Quarters French Door Replacement Cheyenne River Health Center 24276 166th St, Eagle Butte, SD 57625 The Indian Health Service (IHS) is conducting a SOURCES SOUGHT/REQUEST FOR INFORMATIO... Cheyenne River Quarters French Door Replacement Cheyenne River Health Center 24276 166th St, Eagle Butte, SD 57625 The Indian Health Service (IHS) is conducting a SOURCES SOUGHT/REQUEST FOR INFORMATION as outlined in FAR 15.201(c)(3) to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses (Indian Economic Enterprise (IEE)), 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. Interested firms are requested to reply to this announcement with a submittal as described below. Please note that a decision not to submit a response to this request for information will not preclude a vendor from participating in any future solicitation. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS RFI. THIS IS NOT A SOLICITATION FOR PROPOSALS. Respondents will NOT be notified of the results of this notice. No reimbursement will be made for any costs associated with providing information in response to this notice or any follow-up information requested. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. SUMMARY OF SCOPE The contractor shall provide all labor, materials, supplies, and services to remove and replace doors for 113 quarters for the Cheyenne River Health Center. Work shall include repair and painting drywall near door frame and ensuring doors are keyed to match existing system. In accordance with FAR 36.204, Disclosure of the Magnitude of Construction Projects, the anticipated project magnitude is between $500,000.00 and $1,000,000.00 The type of work to be performed will be categorized under PSC code Y1DA, Construction of Hospitals and Infirmaries and NAICS code 236220, Commercial and Institutional Building Construction with a size standard of $45 million. RESPONSES - SUBMITTAL Responses to this notice must be emailed to Thupten Tsering at thupten.tsering@ihs.gov and must be received no later than published due date and time. Responses must include: Company Information: Company name, website, physical address, SAM UEI code Point of Contact: Contact name, phone number, and E-mail address If a solicitation is issued, will your firm/company be submitting a proposal? Indicate Yes or No Type of Business: Native American-owned (IEE/ISBEE), SBA certified 8(a), SBA Certified HUB Zone, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Women Owned Small Business (WOSB), and/or Small Businesses (SB). For more information on the definitions or requirements for these small business programs, refer to http://www.sba.gov. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities. Experience Submission Requirements: Submit at least two (2) but no more than five (5) projects completed by your firm within the last six (6) years that are similar to the work that will be required under this project. Firms shall describe, in detail, how projects are similar and include the following information for each project: Indicate whether Prime Contractor or Subcontractor for each project submitted; Dates of construction for each project submitted; Contract value, location, completion date, and complexity of job for each project submitted; Indicate whether the project is a federal, state, tribal or other for each project submitted; and Project references/Agency point of contact (telephone number and email address) for each project submitted. If the entity responding to this sources sought is submitting experience information from any entity that does not match the name, CAGE code, and/ or UEI exactly as stated on the submitting entity’s SAM record (e.g. affiliates, subsidiaries, parent companies, sister companies, etc.) the submission shall clearly demonstrate how that entity will have meaningful involvement in the performance of the contract and specifically address which resources would be committed to the contract. Failure to comply with this requirement or failure to adequately demonstrate meaningful involvement and commitment of resources on behalf of that entity may result in that experience information to be considered not relevant. Along with the project experience submission, the following questions shall be answered in your firms’ submission: How is your company structured to handle quality control of the various disciplines of a construction project? (i.e., what position(s) (full-time/part-time) are employed under your company to perform QC?) Does your company primarily handle the construction activities related to construction management by the prime contractor and if so, what are those activities? Does your company self-perform any of the construction disciplines, if so, what are those disciplines? What disciplines does your company anticipate self-performing for this specific project? For Native American/Indian Owned Businesses only, the contractor shall complete and submit Attachment 1: IHS IEE Representation Form (Jan 2022) along with the controlling enterprise’s Department of the Interior, Bureau of Indian Affairs Certificate of Degree of Indian Blood documentation. Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. All information received in response to this source sought that is marked proprietary will be handled accordingly. Documents and/or information other than what is requested will not be reviewed. Information submitted beyond what is requested will not be considered. QUESTIONS: Questions regarding this sources sought may be emailed to Thupten Tsering at thupten.tsering@ihs.gov