Inactive Total Small Business Set-Aside (FAR 19.5)

Update: Amendment 03 is issued to notify prospecitve bidders of the Contract Specialist change to Taylor Kanthack and to extend the proposal due date to Tuesday July 12, 2022 at 2:00pm pacific time. S... Update: Amendment 03 is issued to notify prospecitve bidders of the Contract Specialist change to Taylor Kanthack and to extend the proposal due date to Tuesday July 12, 2022 at 2:00pm pacific time. See the attachment for details. Update: Amendment 02 is issued to answer pre-proposal inquiries, provide the site visit sign in sheet, change the period of performance of this project, and extend the proposal due date to Tuesday June 21, 2022 at 2:00 pm pacific time. See the attachments for the document. Update: Amendment 01 is issued to correct site visit date to Thursday, May 12, 2022, at 10:00 AM Mountain time. The RFP is released. Please see the attachments to this notice for all of the details. This is a total small business set-aside competition with a preference given to Indian Economic Enterprises (IEE). TITLE: Crow Waste Transfer Stations Renovations ESTIMATED MAGNITUDE OF CONSTRUCTION (APR 1985) (FAR 36.204): The estimated magnitude of the proposed construction is between $500,000 and $1,000,000. PERFORMANCE PERIOD: The performance period for this contract is 150 calendar days from issuance of the Notice to Proceed (NTP). A site visit is scheduled. Please see provision L.8 Site Visit for information.

Inactive Total Small Business Set-Aside (FAR 19.5)

This is a PRESOLICITATION NOTICE, Solicitation 75H70122R00034 for the Crow Waste Transfer Stations Renovations a construction project for the Indian Health Service, Division of Engineering Services. T... This is a PRESOLICITATION NOTICE, Solicitation 75H70122R00034 for the Crow Waste Transfer Stations Renovations a construction project for the Indian Health Service, Division of Engineering Services. The Government anticipates releasing the solicitation on or about 5 May 2022 and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://www.sam.gov/. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://www.sam.gov/. SCOPE OF WORK: The purpose of this project is to provide all services related to the renovation & repair to the Crow Agency, Pryor and St Xavier transfer stations. LOCATION OF PROJECT: All work shall be performed at the Crow Agency, Pryor, St Xavier, in Big Horn County, Montana. CONSTRUCTION DURATION: Period of Performance is 150 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204(g). SITE VISIT: Details regarding the Site Visit will be included in the solicitation. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. This project will be procured as a 100% Small Business set-aside solicitation with a preference for Indian Economic Enterprises (IEEs) under North American Industry Classification System (NAICS) code 237110 Water and Sewer Line and Related Structures Construction. The associated size standard for this procurement is $39.5 million. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. INDIAN OWNED BUSINESSES: For Indian owned businesses, the contractor will be required to complete and submit an attachment entitled, “IHS IEE Representation Form (Jan 2022)”, which will be included with the solicitation, along with your firm’s proposal along with the controlling enterprise’s Tribal enrollment/certificate of Degree of Indian Blood documentation. Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. It is the responsibility of the contractor to check https://www.sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This solicitation will be procured as a Request for Proposals (RFP) in accordance with FAR Part 15 and 36 procedures with Lowest Price Technically Acceptable (LPTA) evaluation criteria. CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. All potential bidders should register with https://www.sam.gov if interested in this forthcoming acquisition. NO ADDITIONAL INFORMATION IS AVAILABLE OTHER THAN WHAT IS NOTED HEREIN. FIRMS ARE INSTRUCTED NOT TO CALL REQUESTING MORE INFORMATION. Interested bidders should follow this pre-solicitation notice on SAM by registering in SAM and clicking on "Follow" to receive notices of any updates to the notice including the posting of the solicitation and any subsequent amendments.

Inactive

75H70122R00034 Sources Sought: Reservation-Wide Transfer Stations Improvements for the Crow Tribe, Crow Reservation in Big Horn County, Montana - Purpose This is a Request for Information (RFI) (SOURC... 75H70122R00034 Sources Sought: Reservation-Wide Transfer Stations Improvements for the Crow Tribe, Crow Reservation in Big Horn County, Montana - Purpose This is a Request for Information (RFI) (SOURCES SOUGHT) as outlined in FAR 15.201(c)(3). The purpose of this sources sought notice is to conduct market research pursuant to FAR Part 10 to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses, 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. This notice is intended strictly for Market Research to determine if a 100% Set Aside for Indian Economic Enterprise (IEE) Firms or if a 100% Set Aside for Small business concerns can fulfill the requirements set forth in this request for information. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS SYNOPSIS. THIS IS NOT A SOLICITATION FOR PROPOSALS. Respondents will NOT be notified of the results of this synopsis. No reimbursement will be made for any costs associated with providing information in response to this synopsis or any follow-up information requested. In accordance with FAR 36.204, Disclosure of the Magnitude of Construction Projects, the anticipated project magnitude is: between $500,000 and $1,000,000. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. This notice is issued solely for information and planning purposes and does not constitute a Request for Proposal (RFP) or a commitment on the part of the government to conduct a solicitation for the stated services in the future. Responders are advised that the government will not pay for information submitted in response to this RFI, nor will it compensate responders for any costs incurred in the development/furnishing of a response. Please note that a decision not to submit a response to this RFI will not preclude a vendor from participating in any future solicitation. Firms are requested to reply to this announcement with a response to the specialized qualifications listed below. Based upon the responses received from IEE businesses, consideration will be given to determine if this acquisition can be set-aside for IEE business competition. The type of work to be performed will be categorized under PSC code: Z2ND; Repair Or Alteration Of Sewage and Waste Facilities and NAICS code: 237110; Water and Sewer Line and Related Structures Construction with a size standard of $36.5 million. - Description/Scope of Work The purpose of this project is for a contractor to furnish all labor, personnel, materials, equipment, tools, appliances, supplies, services, permits, insurance, supervision, and facilities for the renovation and repairs to three existing transfer stations on the Crow Reservation for the Crow Tribe, in Big Horn County, Montana, to include: Crow Agency Transfer Station (Excavation, Retaining wall repairs, Trash chute installation, Pedestrian and vehicle barrier rails, New sorting bays & Chain link fence & gate) Pryor Transfer Station (Retaining wall repairs, Trash chute installation, Pedestrian and vehicle barrier rails, New sorting bays & Chain link fence & gate) St Xavier Transfer Station (Retaining wall repairs, Trash chute installation, Pedestrian and vehicle barrier rails, New sorting bays & Chain link fence & gate) - RESPONSES - SUBMITTAL Responses must be limited to five (5) letter-size pages or less, in Microsoft Word or Portable Document format (PDF). Include the following: 1. Company Information: Provide your firms contact information to include DUNS and SAM UEI, CAGE code, name, address, and point of contact with verifiably correct telephone number and email address. 2. Indicate if a solicitation is issued will your firm/company be submitting a proposal (Yes/No) 3. Type of Business: Native American-owned (IEE/ISBEE), SBA certified 8(a), SBA Certified HUB Zone, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Women Owned Small Business (WOSB), and/or Small Businesses (SB). For more information on the definitions or requirements for these small business programs, refer to http://www.sba.gov. a. INDIAN OWNED FIRMS: For Indian owned business, the following form shall be completed and submitted along with your firm’s response: “IHS IEE Representation Form Jan 2022” along with the controlling enterprise’s Tribal enrollment/certificate of Degree of Indian Blood documentation. Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. 4. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities. 5. Experience Submission Requirements: Submit at least two (2) but no more than five (5) similar projects completed within the last seven (7) years that are relevant to the work that will be required under this project. Firms shall include the following information: a. Indicate whether Prime Contractor or Subcontractor for each project submitted; b. Dates of construction for each project submitted; c. Contract value, location, completion date, and complexity of job for each project submitted; d. Indicate whether the project is a federal, state, tribal or other for each project submitted; and e. Project references/Agency point of contact (telephone number and e-mail address) for each project submitted. - Restrictions on Response Questions regarding this RFI shall be emailed to Nicholas A. Aprea, Contracting Specialist Nicholas.Aprea@ihs.gov and Jenny Scroggins, Contracting Officer at Jenny.Scroggins@ihs.gov . Telephone solicitations and questions will not be entertained. This Sources Sought is for informational and planning purposes ONLY and is not to be construed as a commitment by the Government nor will the Government pay for any information solicited. Since this is a Sources Sought announcement, no evaluation letters and/or results will be issued to the respondents. - How to Respond Please submit your response no later than 29 March, 2022 at 5:00PM Central Time. Please enter "Reservation Wide Transfer Stations Improvements, Crow Tribe, Crow Reservation" into the email subject field.