Inactive Total Small Business Set-Aside (FAR 19.5)

See attached for Solicitation 75H70122R00026 Prairie Village Sewer Renovation for construction services prepared in accordance with FAR Part 36. These construction services are in support of the India... See attached for Solicitation 75H70122R00026 Prairie Village Sewer Renovation for construction services prepared in accordance with FAR Part 36. These construction services are in support of the Indian Health Service (IHS). A full scope of work, plans and specifications and Construction Wage Determination are included in the solicitation documents. Additional details can be found in the solicitation. This project will be advertised as a 100% Small Business set-aside with preference to Indian Economic Enterprise (IEE) firms under North American Industry Classification System (NAICS) Code 237110 – Water and Sewer Line and Related Structures Construction. The associated size standard for this procurement is $39.5 million. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the initial notice including any subsequent amendments. SCOPE OF WORK: The Department of Health and Human Services, Indian Health Service (IHS) has determined a need for a contractor to furnish all labor, personnel, materials, equipment, tools, appliances, supplies, services, permits, insurance, supervision, and facilities for the renovate the existing gravity sewer system for the Prairie Village Community. LOCATION OF PROJECT: The Project is to be performed at the following site: Prairie Village Community, located in Anadarko, OK. TERO: TERO fees do not apply. PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed. COnSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204. SITE VISIT: Details regarding the Site Visit are included in the solicitation. CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are required to be registered in SAM when submitting an offer or quotation. The Offeror shall ensure information is current in SAM prior to the response due date. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. *** Amendment 1 Please refer to the attached B05 Amend A0001 for changes to the solicitation. All other terms of the solicitaiton remain unchanged. *** Amendment 2 Pleaes refer to the attached B05 Amend A0002 for changes to the solicitation. The due date is being extended to 28 April 2022 at 2:00PM PDT. All other terms of the solicitation remain unchanged.

Inactive Total Small Business Set-Aside (FAR 19.5)

This is a Pre-Solicitation Notice for Solicitation 75H70122R00026 Prairie Village Sewer Renovation for construction services prepared in accordance with FAR Part 36. These construction services are in... This is a Pre-Solicitation Notice for Solicitation 75H70122R00026 Prairie Village Sewer Renovation for construction services prepared in accordance with FAR Part 36. These construction services are in support of the Indian Health Service (IHS). The Government anticipates releasing the solicitation on or about 23 March 2022 and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://sam.gov/. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://sam.gov/. This project will be advertised as a 100% Small Business set-aside with preference to Indian Small Business Economic Enterprise (ISBEE)/Indian Economic Enterprise (IEE) firms under North American Industry Classification System (NAICS) Code 237110 – Water and Sewer Line and Related Structures Construction. The associated size standard for this procurement is $39.5 million. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the initial notice including any subsequent amendments. No additional information is available other than what is noted herein. Firms are instructed not to call requesting more information. SCOPE OF WORK: The Department of Health and Human Services, Indian Health Service (IHS) has determined a need for a contractor to furnish all labor, personnel, materials, equipment, tools, appliances, supplies, services, permits, insurance, supervision, and facilities for the renovate the existing gravity sewer system for the Prairie Village Community. LOCATION OF PROJECT: The Project is to be performed at the following site: Prairie Village Community, located in Anadarko, OK. TERO: TERO fees do not apply. PERIOD OF PERFORMANCE: The contract Period of Performance is 180 calendar days from date of notice of proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $500,000 and $1,000,000, in accordance with FAR 36.204. SITE VISIT: Details regarding the Site Visit will be included in the solicitation. CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable evaluation criteria. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties.

Inactive

This is a Request for Information (RFI) (SOURCES SOUGHT) as outlined in FAR 15.201(c)(3) and is to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses inc... This is a Request for Information (RFI) (SOURCES SOUGHT) as outlined in FAR 15.201(c)(3) and is to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses, 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. This notice is intended strictly for Market Research to determine if a 100% Set Aside for Indian Economic Enterprise (IEE) Firms or if a 100% Set Aside for Small business concerns can fulfill the requirements set forth in this request for information. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS SYNOPSIS. THIS IS NOT A SOLICITATION FOR PROPOSALS. Respondents will NOT be notified of the results of this synopsis. No reimbursement will be made for any costs associated with providing information in response to this synopsis or any follow-up information requested. In accordance with FAR 36.204, Disclosure of the Magnitude of Construction Projects, the anticipated project magnitude is between $500,000 and $1,000,000. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. This notice is issued solely for information and planning purposes and does not constitute a Request for Proposal (RFP) or a commitment on the part of the government to conduct a solicitation for the stated services in the future. Responders are advised that the government will not pay for information submitted in response to this RFI, nor will it compensate responders for any costs incurred in the development/furnishing of a response. Please note that a decision not to submit a response to this RFI will not preclude a vendor from participating in any future solicitation. Firms are requested to reply to this announcement with a response to the specialized qualifications listed below. Based upon the responses received from IEE businesses, consideration will be given to determine if this acquisition can be set-aside for IEE business competition. The type of work to be performed will be categorized under PSC code Z2ND Repair or Alteration of Sewage and Waste Facilities and NAICS code 237110 Water and Sewer Line Related Structures Construction with a size standard of $39.5 million. Description/Scope of Work The purpose of this project is for a contractor to furnish all labor, personnel, materials, equipment, tools, appliances, supplies, services, permits, insurance, supervision, and facilities for the renovate the existing gravity sewer system for the Prairie Village Community located in Anadarko, OK, which serves Native Americans in the City of Anadarko RESPONSES - SUBMITTAL Responses must be limited to five (5) letter-size pages or less, in Microsoft Word or Portable Document format (PDF). Include the following: Company Information: Provide your firms contact information to include DUNS and SAM UEI, cage code, name, address, and point of contact with verifiably correct telephone number and email address. Indicate if a solicitation is issued will your firm/company be submitting a proposal (Yes/No) Type of Business: Native American-owned (IEE/ISBEE), SBA certified 8(a), SBA Certified HUB Zone, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Women Owned Small Business (WOSB), and/or Small Businesses (SB). For more information on the definitions or requirements for these small business programs, refer to http://www.sba.gov. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities. Experience Submission Requirements: Submit at least two (2) but no more than five (5) similar projects completed within the last seven (7) years that are relevant to the work that will be required under this project. Firms shall include the following information: a. Indicate whether Prime Contractor or Subcontractor for each project submitted; b. Dates of construction for each project submitted; c. Contract value, location, completion date, and complexity of job for each project submitted; d. Indicate whether the project is a federal, state, tribal or other for each project submitted; and e. Project references/Agency point of contact (telephone number and e-mail address) for each project submitted. Restrictions on Response Questions regarding this RFI shall be emailed to Taylor Kanthack, Contracting Specialist taylor,kanthack@ihs.gov and Jenny Scroggins, Contracting Officer at jenny.scroggins@ihs.gov . Telephone solicitations and questions will not be entertained. This Sources Sought is for informational and planning purposes ONLY and is not to be construed as a commitment by the Government nor will the Government pay for any information solicited. Since this is a Sources Sought announcement, no evaluation letters and/or results will be issued to the respondents. How to Respond Please submit your response no later than 28 February, 2022 at 3:00PM Pacific Standard Time. Please enter "Prairie Village Sewer Renovation" into the email subject field.