Inactive Total Small Business Set-Aside (FAR 19.5)

Amendment No. A0002 issued August 21, 2020. Amendment No. A0001 issued August 17, 2020. The project will include the design and construction of a residential duplex that will be used as staff housing ... Amendment No. A0002 issued August 21, 2020. Amendment No. A0001 issued August 17, 2020. The project will include the design and construction of a residential duplex that will be used as staff housing by the IHS staff serving the Kyle Health Center in Kyle, South Dakota One unit of the duplex shall provide one bedroom. The other unit of the duplex shall provide two bedrooms. The one-bedroom unit shall be 725 square feet in size. The two-bedroom unit shall be 950 square feet in size and accessible per Architectural Barriers Act (ABA) standards. The duplex shall be located on a lot within the existing Kyle Staff Housing Area. The original housing in this area was constructed in 1990. Utilities including water, sewer, electricity, telephone and cable television are available in the street directly in front of the lot. The duplex shall be designed with approximately the same general exterior appearance and finish as existing adjacent units. Each unit shall provide a living area, dining area, kitchen, bathroom, laundry room/space, mechanical space and single vehicle separated garage. Both garages may be attached to each other. Each unit shall have yards separated with five-foot-tall residential duty chain-link fences extending around the perimeter of the site with approximately the same configuration, construction and materials as existing adjacent units.

Inactive Total Small Business Set-Aside (FAR 19.5)

This is a PRESOLICITATION NOTICE, Solicitation 75H701-20-R-00044 for the Kyle Health Center Duplex Project, a construction project for the Indian Health Service, Division of Engineering Services. The ... This is a PRESOLICITATION NOTICE, Solicitation 75H701-20-R-00044 for the Kyle Health Center Duplex Project, a construction project for the Indian Health Service, Division of Engineering Services. The Government anticipates releasing the solicitation on or about 29 July 2020 and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://beta.sam.gov/. A full scope of work, plans and specifications and Davis Bacon Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://beta.sam.gov/. SCOPE OF WORK: The project will include the design and construction of a residential duplex that will be used as staff housing by the IHS staff serving the Kyle Health Center in Kyle South Dakota. One unit of the duplex shall provide one bedroom. The other unit of the duplex shall provide two bedrooms. The one-bedroom unit shall be 725 square feet in size. The two-bedroom unit shall be 950 square feet in size and accessible per Architectural Barriers Act (ABA) standards. The duplex shall be located on a lot within the existing Kyle Staff Housing Area. The original housing in this area was constructed in 1990. Utilities including water, sewer, electricity, telephone and cable television are available in the street directly in front of the lot. The duplex shall be designed with approximately the same general exterior appearance and finish as existing adjacent units. Each unit shall provide a living area, dining area, kitchen, bathroom, laundry room/space, mechanical space and single vehicle separated garage. Both garages may be attached to each other. Each unit shall have yards separated with five-foot-tall residential duty chain-link fences extending around the perimeter of the site with approximately the same configuration, construction and materials as existing adjacent units. LOCATION OF PROJECT: All work shall be performed at the Kyle Health Center, 1000 Health Center Road, Kyle, SD 57752. Kyle Health Center is located on the Pine Ridge Reservation. Work included under this contract will be in Oglala Lakota County, South Dakota. CONSTRUCTION DURATION: Period of Performance is 583 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $250,000 and $500,000, in accordance with FAR 36.204(g). SITE VISIT: Details regarding the Site Visit will be included in the solicitation. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. This project will be procured as a 100% Small Business set-aside solicitation under North American Industry Classification System (NAICS) code 236115, New Single Family Housing Construction. The associated size standard for this procurement is $39.5 million. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $39.5 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://beta.sam.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This solicitation will be procured as a Request for Proposals (RFP) in accordance with FAR Part 15 and 36 procedures with Lowest Price Technically Acceptable evaluation criteria. CONTRACT TYPE: The Indian Health Service intends to award a Firm Fixed Price (FFP) design-build construction contract in support of this requirement. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. All potential bidders should register with https://beta.sam.gov if interested in this forthcoming acquisition. NO ADDITIONAL INFORMATION IS AVAILABLE OTHER THAN WHAT IS NOTED HEREIN. FIRMS ARE INSTRUCTED NOT TO CALL REQUESTING MORE INFORMATION. Interested bidders should register and follow this pre-solicitation notice on https://beta.sam.gov to receive email notices of any updates to the notice including the posting of the solicitation and any subsequent amendments.

Inactive

This is a SOURCES SOUGHT SYNOPSIS ONLY. The purpose of this synopsis is to gain knowledge of interest, capabilities and qualifications of firms, especially small businesses including: Native American/... This is a SOURCES SOUGHT SYNOPSIS ONLY. The purpose of this synopsis is to gain knowledge of interest, capabilities and qualifications of firms, especially small businesses including: Native American/Indian-Owned Businesses, 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUBZone) Small Businesses, Small Businesses (SBs), Women-Owned Small Businesses (WOSBs), Service Disabled Veteran-Owned Small Business (SDVOSBs), Small Disadvantaged Businesses (SDBs) and Veteran Owned Small Businesses (VOSBs). The interest of “other than small business” is also requested. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS SYNOPSIS. THIS IS NOT A SOLICITATION FOR PROPOSALS AND NO CONTRACT WILL BE AWARDED FROM THIS SYNPOSIS. Respondents will NOT be notified of the results of this synopsis. No reimbursement will be made for any costs associated with providing information in response to this synopsis or any follow-up information requested. Please note that a decision not to submit a response to this RFI will not preclude a vendor from participating in any future solicitation. The government is seeking firms under the North America Industry Classification System (NAICS) Code 236115, New Single-family Housing Construction, with a size standard of $39.5 million. In accordance with FAR 36.204, Disclosure of the Magnitude of Construction Projects, the anticipated project magnitude is between $250,000 and $500,000. Description/Scope of Work: The Department of Health and Human Services, Indian Health Service (IHS) anticipates an acquisition for the design and construction of one residential duplex (with two living units) to be used as IHS staff housing serving the Kyle Health Center in Kyle, South Dakota using the design-build method. One unit of the duplex shall provide one bedroom. The other unit of the duplex shall provide two bedrooms. The one-bedroom unit shall be 725 square feet in size. The two-bedroom unit shall be 950 square feet in size and accessible per Architectural Barriers Act (ABA) standards. The duplex shall be located on a lot within the existing Kyle Staff Housing Area. The original housing in this area was constructed in 1990. Utilities including water, sewer, electricity, telephone and cable television are available in the street directly in front of the lot. The duplex shall be designed with approximately the same general exterior appearance and finish as existing adjacent units. Each unit shall provide a living area, dining area, kitchen, bathroom, laundry room/space, mechanical space and single vehicle separated garage. Both garages may be attached to each other. Each unit shall have yards separated with five-foot-tall residential duty chain-link fences extending around the perimeter of the site with approximately the same configuration, construction and materials as existing adjacent units. The Design Build (DB) Contractor will be required to perform all work, furnish all personnel, materials, professional services, other services, facilities and all other necessary incidentals necessary to design and construct the Kyle Staff Quarters Duplex. The design and construction shall be performed in accordance with the latest published edition, codes, standards, and guidelines identified in IHS 2019 Architect-Engineer Design Guide and as described in the Statement of Work. The DB Contractor shall be responsible for all disciplines of design including but not limited to architectural, structural, civil, mechanical, plumbing and electrical. The estimated period of performance is 583 calendar days (218 for design and 365 for construction). Submission Package: Interested Contractors are invited to submit a capabilities statement/narrative demonstrating the firm’s experience in design and construction projects of a similar nature as described above. The submittal shall be no longer than ten (10) letter-size pages and shall include the following: 1. Cover letter/sheet that includes: a. Your firm's Data Universal Numbering System (DUNS) number, b. CAGE code (if applicable), c. Company point of contact (POC) and d. Socioeconomic status under North American Industry Classification System (NAICS) code 237110 (i.e., SBA Certified 8(a), SBA Certified HUBZone, SDB, SDVOSB, WOSB, Native American Owned, etc.), and any other relevant/appropriate data. 2. Indicate if a solicitation is issued, will your firm be submitting a proposal (Yes/No) 3. General Business Information: Provide general information about your business, to include any relevant information pertaining to the requirement. 4. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities. 5. Experience: Submit at least two (2) but no more than five (5) of similar projects completed within the last ten (10) years that are relevant to the work that will be required under this project. Firms shall include the following information: a. Indicate whether Prime Contractor or Subcontractor for each project submitted; b. Dates of construction for each project submitted; c. Contract value, location, completion date, and complexity of job for each project submitted; d. Indicate whether the project is a federal, state, tribal or other for each project submitted; and e. Project references/Agency point of contact (telephone number and e-mail address) for each project submitted. 6. Past Performance: Provide past performance on contracts with government agencies and private industry similar in size, scope and complexity to the instant project in terms of cost control, quality of work and compliance with performance schedules. Questions Questions regarding this synopsis shall be emailed to Shaukat Syed, Contracting Officer at shaukat.syed@ihs.gov. Telephone solicitations and questions will not be entertained. This sources sought is for informational and planning purposes ONLY and is not to be construed as a commitment by the Government nor will the Government pay for any information solicited. Since this is a sources sought synopsis, no evaluation letters and/or results will be issued to the respondents. How to Respond EMAIL RESPONSES ARE REQUIRED BY JULY 13, 2020 at 2:00PM Central Time. Electronic versions of your submission package of ten (10) PAGES OR LESS, shall be submitted VIA EMAIL to Shaukat Syed, email: shaukat.syed@ihs.gov. Please enter "Kyle Staff Quarters Duplex" into the email subject field. AGAIN, THIS IS NOT A REQUEST FOR PROPOSALS. This is for planning purposes only and is a market research tool to determine availability and adequacy of potential sources particularly Small Business Sources. The Government will not reimburse responders for the cost of the submittals.