Inactive

Site-Adapt Construction Requirement Solicitation No. W912ER21R0024 - Aqoura National Training & Operational Center (ANTOC) Lebanon Notes: (a) The Government reserves the right to incorporate the award... Site-Adapt Construction Requirement Solicitation No. W912ER21R0024 - Aqoura National Training & Operational Center (ANTOC) Lebanon Notes: (a) The Government reserves the right to incorporate the awardee proposal into the contract and distribute the proposal as deemed necessary. Any deviations from the proposal must be approved by the Contracting Officer. (b) The contractor is required to provide all documentation requested in this solicitation to include Defense Base Act (DBA) Insurance after contract award and prior to the full Notice to Proceed. (c) A Bank Letter of Guarantee will be required for this acquisition in accordance w ith the guidance at Section 00 73 00 Special Contract Requirements. Please refer to the attached Solicitation Form 1442 - W912ER21R0024, CDC Specifications, CDC Drawings, Cost Breakdown Sheet and Proposal Schedule for further details on submission requirements.

Inactive

United States Army Corp of Engineers, Middle East District, Construction of a Design-Bid-Build (DBB) Firm Fixed Price contract. Pre-Solicitation Notice for W912ER21R0024 Anticipated Solicitation Issue... United States Army Corp of Engineers, Middle East District, Construction of a Design-Bid-Build (DBB) Firm Fixed Price contract. Pre-Solicitation Notice for W912ER21R0024 Anticipated Solicitation Issue Date: June 1 - Mid June 2021 Anticipated Solicitation Response Date: Mid July 2021 Set Aside: As the work will be performed outside of the continental United States, no set asides to small business or socioeconomic preference for this solicitation. NAICS: 236220 – Commercial and Institutional Building Construction Contracting Office Address: US Army Corp of Engineers – Middle East District, P.O. Box 2250, Winchester, VA 22604-1450 SYNOPSIS: TAM is anticipating a Design-Bid-Build (DBB), firm fixed price (FFP), award for the construction of a slab on grade (reinforced concrete pad) and associated site work and grading. This project will be constructed within the Aquora National Training & Operational Center (ANTOC) in Lebanon. A firm fixed price contract will be awarded to a prime construction contractor. PROJECT SCOPE: This Design-Bid-Build (DBB) project consists of the construction of a slab on grade, in its entirety is 26.5 x 15.3 meters (87'- 0" X 50’.2”). Site work includes the following: grading and preparing of surface as indicated by drawings. Grading and compacting access as indicated by RFP drawings. Optional Work: Option #1 – Concrete Masonry Unit (CMU) Structure to include a CMU and metal truss structure dimensions 11,600mm X 15,744mm (38’-0” x 52’-0”). Option #2 – Access Road Aggregate to include surfacing graded access road with 6” of aggregate surfacing. The Period of Performance is anticipated to be 365 days from issuance of notice to proceed. The magnitude of the ANTOC construction projects is between $1,000,000.00 ($1M) - $5,000,000.00 ($5M) Proposal Procedures: The Request for Proposal (RFP) will be issued on beta.SAM.GOV. It is anticipated that the lowest price technically acceptable (LPTA) contracting method will be used to evaluate proposals. Evaluation criteria will be stated in the RFP. This acquisition will result in a single-fixed price construction contract award based on the LPTA determination. Site visit information will be stated in the RFP. Due to COVID travel restrictions please ensure that you are able to gain access to Lebanon for the site visit. Qualification Criteria: In order to be found eligible for this award of this requirement, the offeror must meet the following criteria: The Offeror shall be registered and approved in the System for Award Management (SAM) https://www.sam.gov. SAM is the official website required in order to do business with the U.S. Government. The offeror shall have the means to obtain financial surety for this project through US Treasury bonds, Irrevocable Letter of Credit (ILCs) or other means. The respondent must outline their plan for obtaining financial surety as part of the required submittals detailed below. The location for this requirement is in the country of Lebanon. The offeror must demonstrate a working understanding of the necessary access requirements for Lebanese Armed Forces (LAF) facilities. As security requirements are subject to change, it will be the Contractor's responsibility to meet current security requirements necessary to both obtain and maintain access to LAF military facilities. The potential Offeror shall possess the capability to pass all mandatory physical and logistical admittance requirements to be granted entrance to the country of Lebanon. This includes any and all requirements related to COVID-19 Restrictions. Base life support on the construction site will not be available. The Contractor shall have responsibility for all Life Support items (food, lodging and transportation to the worksite) for their workforce. The Offeror shall have the capability to exercise rapid deployment and portability options with minimal operation disruption, secure habitability and physical security. The construction site for this requirement will be at an undisclosed location within the country of Lebanon. The location is difficult to access as it is in a very remote, mountainous geographical location at high altitude which is snow covered for much of the calendar year. Therefore, the offeror must have the means, or means to arrange for, unconventional transportation methods (i.e. other than a ground vehicle) to the project location. If required, the Offeror must be able to ship to the OCONUS location, all products, materials, and equipment; complete customs clearance and be delivered to the designated destination within the Period of Performance PoP). RESPONSE PERIOD: This is a pre-solicitation notice only and is not a request for proposal (RFP) nor does it restrict the Government as to the ultimate acquisition approach. The Government will not reimburse respondents for any costs incurred in preparation of a response to this notice. Questions can be sent to Maria Rodeffer, email: Maria.C.Rodeffer@usace.army.mil and Elizabeth Tedrow, email: Elizabeth.C.Tedrow@usace.army.mil

Inactive

United States Army Corps of Engineers (USACE) Transatlantic Middle East District (TAM) has a requirement at the Aquora National Training & Operational Center (ANTOC) in Lebanon. This requirement will ... United States Army Corps of Engineers (USACE) Transatlantic Middle East District (TAM) has a requirement at the Aquora National Training & Operational Center (ANTOC) in Lebanon. This requirement will be in the form of a Design-Bid-Build (DBB), Firm Fixed Price (FFP) contract. The scope of the requirement will consist of a slab on grade (reinforced concrete pad). The dimensions for the slab on grade, in its entirety, shall be 26.5 x 15.3 meters (87’-0” x 50’.2”). This requirement will also include an optional bid item for the construction of a Concrete Masonry Unit (CMU) structure. The CMU structure dimensions shall be 11,600mm x 15,744mm (38’-0” x 52’-0”). The estimated Magnitude of Construction for this project is between $500,000.00 and $1,000,000.00 United States (US) Dollars, with a period of performance (POP) of three hundred and sixty five (365) calendar days. The NAICS code for this project will be 236220 - Commercial and Institutional Building Construction. The Classification code for this project will be Y1JZ – Construction of Miscellaneous Buildings. The solicitation will be a request for proposal (RFP). The Government will use full and open competition procedures, with the consideration of one of two evaluation methods for this requirement: Lowest Price Technically Acceptable (LTPF) or Best Value Tradeoff (BVTO) source selection process to evaluate proposals. Evaluation criteria will be stated in the RFP when issued. The Government reserves the right to cancel this requirement either before or after the submittal date listed below. Therefore there is no legal liability on the part of the Government, to include liability for any costs associated with the Contractor’s preparation of a Capabilities Statement. Qualification Criteria: In order to be found eligible for award of this requirement, the offeror must meet the following criteria: The Offeror shall be registered and approved in the System for Award Management (SAM) at https://www.sam.gov. SAM is the official website required in order to do business with the U.S. Government. The offeror shall have the means to obtain financial surety for this project through US Treasury bonds, Irrevocable Letter of Credit (ILCs) or other means. The respondent must outline their plan for obtaining financial surety as part of the required submittals detailed below. The location for this requirement is in the country of Lebanon. The offeror must demonstrate a working understanding of the necessary access requirements for Lebanese Armed Forces (LAF) facilities. As security requirements are subject to change, it will be the Contractor's responsibility to meet current security requirements necessary to both obtain and maintain access to LAF military facilities. The potential Offeror shall possess the capability to pass all mandatory physical and logistical admittance requirements to be granted entrance to the country of Lebanon. This includes any and all requirements related to COVID-19 Restrictions. Base life support on the construction site will not be available. The Contractor shall have responsibility for all Life Support items (food, lodging and transportation to the worksite) for their workforce. The Offeror shall have the capability to exercise rapid deployment and portability options with minimal operation disruption, secure habitability and physical security. The construction site for this requirement will be at an undisclosed location within the country of Lebanon. The location is difficult to access as it is in a very remote, mountainous geographical location at high altitude which is snow covered for much of the calendar year. Therefore, the offeror must have the means, or means to arrange for, unconventional transportation methods (i.e. other than a ground vehicle) to the project location. If required, the Offeror must be able to ship to the OCONUS location, all products, materials, and equipment; complete customs clearance and be delivered to the designated destination within the Period of Performance PoP). Capabilities Statement Instructions: All capability statements submitted in response to this Sources Sought notice must meet the following requirements: Capability Statement must be no more than five (5) pages in length. 2.The Offeror must provide confirmation that the contractor meets all required qualification criteria listed above. 3.Per the qualification criteria listed above, the contractor must provide what type of financial surety they are capable of obtaining and the process for doing so. 4.The offeror must provide one (1) project example, along with any associated photographs (if applicable), that best illustrates the proposed contractor’s qualification to execute this requirement. 5.Any additional information the offeror feels is relevant to this requirement. Closing Deadline for Submissions: Your response is due no later than Wednesday, 14 April, 2021, 4:00PM (Eastern Standard Time). Please submit your response via email and place the words “Market Research for W912ER21R0024” on the subject line of your message. Please send your submission to the undersigned Contracting Officer at maria.c.rodeffer@usace.army.mil, MSG Shantae Allen at shantae.r.allen@usace.army.mil, and Elizabeth Tedrow at elizabeth.c.tedrow@usace.army.mil.