Inactive Total Small Business Set-Aside (FAR 19.5)

NAICS Code: 562910 Remediation Services PSC: F108 Environmental systems protection-environmental remediation (including Hazardous Substance Removal, Cleanup, and Disposal Services and Operational Supp... NAICS Code: 562910 Remediation Services PSC: F108 Environmental systems protection-environmental remediation (including Hazardous Substance Removal, Cleanup, and Disposal Services and Operational Support) This Request for Quote (RFQ) is being solicited to Total Small Business Set-Aside. 1. The Contract Completion Date will be set at: 120 days after issuance of the Notice to Proceed. 2. One site visit is scheduled for: Contractor will meet Gov. Representative at the Mainside Visitor Control Center parking lot on Wednesday, January 29, 2025, at 0900 AM local time SHARP. RSVP for sight visit NLT Tuesday, January 28, 2025 at 1100AM to Frank Harrison at email frank.b.harrison.civ@us.navy.mil providing the Company name and name of attendees. Do NOT go directly to the project site. All attendees will be escorted in a van provided by the Government. 3. Quote is due no later than 11:00 AM EST sharp Friday, February 14, 2025. RFIs due to Joseph Henrius joseph.p.henrius.civ@us.navy.mil & Shelley Toribio shelley.a.toribio.civ@us.navy.mil NLT February 12, 2025 at 1100AM Only electronic proposals are acceptable and must be e-mailed to Shelley Toribio at shelley.a.toribio.civ@us.navy.mil . 4. Contractors may experience delays at the gates when entering and/or exiting the installation. The Government shall not compensate for any such delays. All vehicles are subject to search upon entry, exit and while on the installation. Refusal to comply with a DoD police request to search a vehicle will result in denial of access to the installation and may result in criminal prosecution. 5. All terms and conditions from this solicitation shall be included in the awarded contract by reference.

Inactive Total Small Business Set-Aside (FAR 19.5)

NAICS Code: 562910 Remediation Services PSC: F108 Environmental systems protection- environmental remediation (Including Hazardous Substance Removal, Cleanup, and Disposal Services and Operational Sup... NAICS Code: 562910 Remediation Services PSC: F108 Environmental systems protection- environmental remediation (Including Hazardous Substance Removal, Cleanup, and Disposal Services and Operational Support) This Sources Sought notice is for informational and planning purposes only and shall not be construed as a solicitation or as an obligation or commitment by the Government. This notice is intended strictly for market research. The purpose of the Sources Sought notice is to determine interest and capability of potential qualified vendors relative to the North American Industry Classification System (NAICS) codes of 562910 (Remediation Services). All responsible sources may submit a capability statement, as described below, which shall be considered by the agency. The Government is seeking responses to this sources sought synopsis from all interested businesses capable of providing the requirement. Small business, in all socioeconomic categories (including, 8(a) Business Development Program, Historically Underutilized Business Zone, Service Disabled Veteran-Owned, Women-Owned Small Business, etc.) are highly encouraged to identify capabilities in meeting the requirements at fair market prices. Provide suggestions on how the requirement could be structured to facilitate competition by and among small business concerns. Describe any conditions, if any that may limit small businesses from participation. Responses are to be sent via email to Shelley Toribio at shelley.a.toribio.civ@us.navy.mil no later than 11:00 AM on 27 January 2025. Interested respondents should submit a brief capabilities statement package (no more than 2 pages in length, single spaced, 12 point font minimum) clearly demonstrating the firm's ability to perform this requirement. A generic capability statement is not acceptable. Please review the requirements listed below. At a minimum, the package shall address the following: 1. Title of the requirement; Company Name; Address; and Point of Contact (POC) name, phone number, and email address. 2. Company profile to include office location(s), DUNS number/CAGE Code, NAICS, and a statement regarding current small business status to include small business type(s)/certification(s) such as: 8a, WOSB, EDWOSB, HUBZone, SDVOSB, etc. 3. Specific experience (private and/or government) in New York, New Jersey, Pennsylvania, and/or Connecticut performing building, utility, and general Mold Remediation, Mold Removal services under the United Facilities General Specifications (UFGS). Statements should describe the dollar value, indicate whether your firm acted as the prime or subcontractor, list a customer Point of Contact with phone number, and provide description of the experience and how the referenced experience relates to the services described herein. A maximum of five (5) project examples reflecting the firm's experience should be submitted. 4. Any suggestions or comments about the NAICS code selection, contract type, or effort in general.