Inactive

NSN 7H-4330-012084990, TDP VER 003, QTY 11 AY, DELIVER TO W62G2T, W1A8 DLA DIST SAN JOAQUIN, TRACY, CA 95304-5000, INDUCTION NIIN IS 7H, 4330, 012084990, BOWL ASSEMBLY, 52812381. The Contract Officer ... NSN 7H-4330-012084990, TDP VER 003, QTY 11 AY, DELIVER TO W62G2T, W1A8 DLA DIST SAN JOAQUIN, TRACY, CA 95304-5000, INDUCTION NIIN IS 7H, 4330, 012084990, BOWL ASSEMBLY, 52812381. The Contract Officer would like to exercise a 45% option quantity within 365-days of the effective date of the repair contract award. The contractor will provide the same delivery time, and will indicate option quantity price. A modification will be completed at the time the option is exercised and all current contract terms and conditions will apply to the option quantity. IMPORTANT NOTE: This RFQ is for repair. Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor will provide the price reduction amount per unit per month the contractor does not meet the RTAT up to a maximum dollar amount. The Government does not own the data or the rights to the data needed to purchase / contract repair of this part from additional sources. It has been determined to be uneconomical to buy the data or rights to the data. It is uneconomical to reverse engineer the part.Interested parties may obtain copies of Military and Federal Specifications and Standards, Qualified Products Lists (QPLs), Qualified Product Databases (QPDs), Military Handbooks, and other standardized documents from the DoD Single Stock Point (DODSSP) at Document Automation and Production Service (DAPS) in Philadelphia, PA. NOTE: Patterns, Drawings, Deviation Lists, Purchase Descriptions, etc. are NOT stocked at DODSSP. Most documents are available in Adobe PDF format from ASSIST-Online at: http://quicksearch.dla.mil/. Users may use ASSIST-Quick Search to search for and download available documents directly using standard browser software. Documents that are not available for downloading from ASSIST-Quick Search can be ordered from the DODSSP website using the ASSIST Shopping Wizard after obtaining a DODSSP Customer Account by following the registration procedures. Users who do not have access to the internet may contact the DODSSP ASSIST Help Desk at 215-697-6396 (DSN: 442-6396), or mail their request to DLA Document Services, Bldg. 4/D, 700 Robbins Avenue, Philadelphia PA 19111-5094. The proposed contract action is for supplies or services for which the Government intends to solicit and negotiate with only one source under the authority of FAR 6.302-1. All responsible sources may identify their interest and capability to respond to the requirement or submit proposals, quotations or capability statements. This notice of intent is not a request for competitive proposals. A determination by the Government not to compete with this proposed contract based upon responses to this notice is solely within the discretion of the Government. Information received will normally be considered solely for the purpose of determining whether to conduct a competitive procurement.Award will be made only if the offeror, the product/service, or the manufacturer meets the qualification requirement(s) at time of award, in accordance with FAR clause 52.209-1. The solicitation identifies the office where additional information can be obtained concerning qualification requirements and is cited in each individual solicitation.Based upon market research, the Government is not using the policies contained in FAR Part 12, Acquisition of Commercial Items, in its solicitation for the described supplies or services. However, interested persons may identify to the contracting officer their interest and capability to satisfy the Government's requirement with a commercial item within 15 days of this notice.

Inactive

NSN 7H-4330-012084990, TDP VER 003, QTY 11 AY, DELIVER TO W62G2T, W1A8 DLA DIST SAN JOAQUIN, TRACY, CA 95304-5000, INDUCTION NIIN IS 7H, 4330, 012084990, BOWL ASSEMBLY, 52812381. The Contract Officer ... NSN 7H-4330-012084990, TDP VER 003, QTY 11 AY, DELIVER TO W62G2T, W1A8 DLA DIST SAN JOAQUIN, TRACY, CA 95304-5000, INDUCTION NIIN IS 7H, 4330, 012084990, BOWL ASSEMBLY, 52812381. The Contract Officer would like to exercise a 45% option quantity within 365-days of the effective date of the repair contract award. The contractor will provide the same delivery time, and will indicate option quantity price. A modification will be completed at the time the option is exercised and all current contract terms and conditions will apply to the option quantity. IMPORTANT NOTE: This RFQ is for repair. Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor will provide the price reduction amount per unit per month the contractor does not meet the RTAT up to a maximum dollar amount. The Government does not own the data or the rights to the data needed to purchase / contract repair of this part from additional sources. It has been determined to be uneconomical to buy the data or rights to the data. It is uneconomical to reverse engineer the part.Interested parties may obtain copies of Military and Federal Specifications and Standards, Qualified Products Lists (QPLs), Qualified Product Databases (QPDs), Military Handbooks, and other standardized documents from the DoD Single Stock Point (DODSSP) at Document Automation and Production Service (DAPS) in Philadelphia, PA. NOTE: Patterns, Drawings, Deviation Lists, Purchase Descriptions, etc. are NOT stocked at DODSSP. Most documents are available in Adobe PDF format from ASSIST-Online at: http://quicksearch.dla.mil/. Users may use ASSIST-Quick Search to search for and download available documents directly using standard browser software. Documents that are not available for downloading from ASSIST-Quick Search can be ordered from the DODSSP website using the ASSIST Shopping Wizard after obtaining a DODSSP Customer Account by following the registration procedures. Users who do not have access to the internet may contact the DODSSP ASSIST Help Desk at 215-697-6396 (DSN: 442-6396), or mail their request to DLA Document Services, Bldg. 4/D, 700 Robbins Avenue, Philadelphia PA 19111-5094. The proposed contract action is for supplies or services for which the Government intends to solicit and negotiate with only one source under the authority of FAR 6.302-1. All responsible sources may identify their interest and capability to respond to the requirement or submit proposals, quotations or capability statements. This notice of intent is not a request for competitive proposals. A determination by the Government not to compete with this proposed contract based upon responses to this notice is solely within the discretion of the Government. Information received will normally be considered solely for the purpose of determining whether to conduct a competitive procurement.Award will be made only if the offeror, the product/service, or the manufacturer meets the qualification requirement(s) at time of award, in accordance with FAR clause 52.209-1. The solicitation identifies the office where additional information can be obtained concerning qualification requirements and is cited in each individual solicitation.Based upon market research, the Government is not using the policies contained in FAR Part 12, Acquisition of Commercial Items, in its solicitation for the described supplies or services. However, interested persons may identify to the contracting officer their interest and capability to satisfy the Government's requirement with a commercial item within 15 days of this notice.