Inactive

CONTACT INFORMATION|4|N771.37|HFB|(717) 605-4262|gregory.c.blissman.civ@us.navy.mil| ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG... CONTACT INFORMATION|4|N771.37|HFB|(717) 605-4262|gregory.c.blissman.civ@us.navy.mil| ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| GENERAL INFORMATION-FOB-DESTINATION|1|TBD| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)|16|COMBO INVOICE AND RECEIVING||TBD|N00104|TBD|TBD|SEE SCHEDULE|SEE SCHEDULE|SEE SCHEDULE||TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|| EQUAL OPPORTUNITY (SEP 2016)|2||| BUY AMERICAN --FREE TRADE AGREEMENTS--BALANCE OF PAYMENTS PROGRAM - BASIC(DEVIATION 2020-O0019) (JUL 2020))|3|||| OPTION FOR INCREASED QUANTITY (MAR 1989)|1|365 DAYS| ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2020)|13|||||||||||||| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM CERTIFICATE (DEVIATION 2020-O0019) (JUL 2020))|3|||| BUY AMERICAN-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (NOV 2014)|1|| ANNUAL REPRESENTATIONS AND CERTIFICATIONS (SEP 2021)|13|333996|1250|||||||||||| NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PERPARDENESS, AND ENRGY PROGAM USE (APRIL 2008))|2||| EVALUATION CRITERIA AND BASIS FOR AWARD-|1|| Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ^^ All freight is FOB Origin. This RFQ is for repair. The resultant award of this solicitation will be issued bilaterally, requiring the contractor's written acceptance prior to execution. Verify nomenclature, part number, and NSN prior to responding. Required Repair Turnaround Time (RTAT): 240 days Government source inspection is required. Please note freight is handled by Navy CAV or Proxy CAV as stated in NAVSUPWSSFA24 or NAVSUPWSSFA25. Your quote should include the following information: Unit Price:__________ Total Price:__________ Check one: Firm-fixed-Price ___ Not to Exceed (Ceiling Price) ___ Estimated___ New unit price:__________ New unit delivery lead-time:__________ T&E fee/price (if asset is determined BR/BER): If an item is determined BR, and the contractor provides documentation that costs were incurred during evaluation and determination of BR, the contracting officer will negotiate a reduced contract price, not-to exceed (NTE) $___________associated with the repair effort to reflect the BR status of the equipment. The T&E fee (if asset is determined BR/BER) was determined based on:______________________________________. Awardee CAGE: __________ Inspection & Acceptance CAGE, if not same as "awardee CAGE": __________ Facility/Subcontractor CAGE (where the asset should be shipped), if not same as "awardee CAGE":__________ Delivery Vehicle (if Delivery Order requested) (if your company has a current BOA/IDIQ, for example) :__________________ The Contract Officer would like to exercise a 100% option quantity within 365-days of the effective date of the repair contract award. The contractor will provide the same delivery turnaround as the base line items. A modification will be completed at the time the option is exercised and all current contract terms and conditions will apply to the option quantity. Please indicate if the Contracting Officer may exercise the 100% option quantity for the repair contract. Yes __ or No __ Please indicate the pricing for the option quantity. Price Each: $___________ IMPORTANT NOTE: Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the following price reduction amount per unit per month the contractor does not meet the RTAT: $__________, up to a maximum of: $_________. \ 1. SCOPE 1.1 This contract/purchase order contains the requirements for repair and the contract quality requirements for the PUMP,CENTRIFUGAL . 2. APPLICABLE DOCUMENTS 2.1 Applicable Documents - The document(s) listed below form a part of this contract/purchase order including modifications or exclusions. 2.1.1 "Document References" listed below must be obtained by the Contractor. Ordering information is included as an attachment to this contract/purchase order. 3. REQUIREMENTS 3.1 Cage Code/Reference Number Items - The PUMP,CENTRIFUGAL repaired under this contract/purchase order shall meet the operational and functional requirements as represented by the Cage Code(s) and reference number(s) listed below. All repair work shall be performed in accordance with the contractors repair/overhaul standard practices, manuals and directives including but not limited to drawings, technical orders, manufacturing operations, tooling instructions, approved repair standards and any other contractor or government approved documents developed to provide technical repair procedures. CAGE___Ref. No. ;10941 998-4213-E-12; 3.2 Marking - This item shall be physically identified in accordance with ;MIL-STD-130, REV N, 16 NOV 2012; . 3.3 Changes in Design, Material Servicing, or Part Number - Except for a Code 1 change, which shall be processed as provided in the code statement shown below, no substitution of items shall be made until the NAVICP-MECH Contracting Officer has notified and approval has been given by issuance of a written change order. When any change in design, material, servicing or part number is made to replace or substitute any item to be furnished on this contract/purchase order, the Contractor shall furnish, for the substituting/replacement item, a drawing and an explanation of the reason for the change, explaining the reason therefor. If finished detail drawings are not available, shop drawings in the form used by the manufacturer will be acceptable for Government evaluation. When notifying the Procurement Contracting Officer of the reasons for making substitutions, the type of change shall be indicated by code number in accordance with one of the following statements: Code 1: PART NUMBER CHANGE ONLY - If the Manufacturer's Part Number indicated thereon has changed, but the parts are identical in all respects, supply the item and advise NAVICP-MECH immediately of the new part number. Code 2: Assembly (or set or kit) not furnished - Used following detail parts. Code 3: Part not furnished separately - Use assembly. Code 4: Part redesigned - Old and new parts are completely interchangeable. Code 5: Part redesigned - New part replaces old. Old part cannot replace new. Code 6: Part redesigned - Parts not interchangeable. 4. QUALITY ASSURANCE 4.1 Responsibility for Inspection - Unless otherwise specified in the contract/purchase order, the Contractor is responsible for the performance of all inspection requirements as specified herein. Except as otherwise specified in the contract/purchase order, the Contractor may use his own or any other facilities suitable for the performance of the inspection requirements specified herein, unless disapproved by the Government. The Government reserves the right to perform any of the inspections set forth in the specification where such inspections are deemed necessary to assure supplies and services conform to prescribed requirements. 4.2 Responsibility for Compliance - All items must meet all requirements of this contract/purchase order. The inspection set forth in this specification shall become a part of the Contractor's overall inspection system or quality program. The absence of any inspection requirements shall not relieve the Contractor of the responsibility of assuring that all products or supplies submitted to the Government for acceptance comply with all requirements of the contract/purchase order. Sampling in quality conformance does not authorize submission of known defective material, either indicated or actual, not does it commit the Government to acceptance of defective material. 4.3 Records - Records of all inspection work by the Contractor shall be kept complete and available to the Government during the performance of contract/purchase order and for a period of 365 calendar days after final delivery of supplies. 4.4 Inspection/Testing Repaired Items - The Contractor shall perform all inspection and testing requirements as specified in the original manufacturer's specifications and drawings. 5. PACKAGING 5.1 Preservation, Packaging, Packing and Marking - Preservation, Packaging, Packing and Marking shall be in accordance with the Contract/Purchase Order Schedule and as specified below. MIL-STD 2073 PACKAGING APPLIES AS FOUND ELSEWHERE IN THE SCHEDULE 6. NOTES 6.1 Ordering Information for Document References - The Department of Defense Single Stock Point (DODSSP), Website http://www.dsp.dla.mil/, provides product information for the Department Of Defense Index Of Specifications and Standards (DODISS) (i.e.Military/Federal Specifications and Standards), Data Item Descriptions (DIDs), and other DODSSP Products. Most Specifications can obtained directly from http://quicksearch.dla.mil/ A. Availability of Cancelled Documents - The DODSSP offers cancelled documentsthat are required by private industry in fulfillment of contractual obligationsin paper format. Documents can be requested by phoning the Subscription Services Desk. B. Commercial Specifications, Standards, and Descriptions - These specifications, standards and descriptions are not available from Government sources. Theymay be obtained from the publishers of the applicable societies. C. Ordnance Standards (OS), Weapons Specifications (WS), and NAVORD OSTD 600 Pages - These type publications may be obtained by submitting a request to: Commander, Indian Head Division, Naval Surface Warfare Center Code 8410P, 101 Strauss Avenue Indian Head, MD 20640-5035 D. On post-award actions, requests for "Official Use Only" and "NOFORN" (Not Releasable To Foreign Nationals) documents must identify the Government ContractNumber, and must be submitted via the cognizant Defense Contract Management Command (DCMC) for certification of need for the document. On pre-award actions such requests must be submitted to the PCO for certification of need for the document. E. NOFORN Military Specifications and Standards (including Amendments, Change Notices and Supplements, but NOT interim Changes) to be ordered from: Contracting Officer NAVSUP-WSS Code 87321 5450 Carlisle Pike P.O. Box 2020 Mechanicsburg, Pa. 17055-0788 F. Nuclear Reactor Publications Assigned NAVSEA Documents and Identification Numbers (i.e. NAVSEA Welding Standard, NAVSEA 250-1500-1) are to be ordered enue: Commanding Officer NAVSUP-WSS Code 009 5450 Carlisle Pike P.O. Box 2020 Mechanicsburg, Pa. 17055-0788 G. Technical Manuals Assigned NAVSEA Identification Numbers (i.e. NAVSEA Welding And Brazing Procedure, NAVSEA S9074-AQ-GIB-010/248) are to be ordered from: Commanding Officer NAVSUP-WSS Code 1 Support Branch 700 Robbins Avenue Philadelphia, Pa. 19111-5094 H. Interim Changes and Classified Specifications must be obtained by submitting a request on DD Form 1425 to NAVSUP-WSS. 6.2 In accordance with OPNAVINST 5510.1 all documents and drawings provided by the U.S. Navy to perspective Contractors must include a "Distribution Statement" to inform the contractor of the limits of distribution, and the safeguarding of the information contained on those documents and drawings. There are 7 (seven) seperate distribution statement codes used for non-classified documents and drawings. The definition for each is as follows: A... approved for public release; distribution is unlimited. B... distribution authorized to US Governments agencies only. C... distribution authorized to US Government agencies and their contractors. D... distribution authorized to DoD and DoD contractors only. E... distribution authorized to DoD Components only. F... further distribution only as directed by Commander, Naval Sea Systems Command, code 09T. X... distribution is authorized to US Government agencies and private individuals or enterprises eligible to obtain export controlled technical data in accordance with OPNAVINST 5510.161. 6.3 Notice To Distributors/Offerors - Consideration for award of contract shall be given only to authorized distributors of the original manufacturer's item represented in this solicitation. If you desire to be considered as a potential source for award of this contract, proof of being an authorized distributor shall be provided on company letterhead signed by a responsible company official and sent with your offer to the Procurement Contracting Officer.

Inactive

NSN 7H-4320-015028206, TDP VER 003, QTY 2 EA, DELIVER TO W25G1U, W1A8 DLA DISTRIBUTION, NEW CUMBERLAND, PA 17070-5002, INDUCTION NIIN IS 7H, 4320, 015028206, PUMP,CENTRIFUGAL, 999-4213-E-13. The Contr... NSN 7H-4320-015028206, TDP VER 003, QTY 2 EA, DELIVER TO W25G1U, W1A8 DLA DISTRIBUTION, NEW CUMBERLAND, PA 17070-5002, INDUCTION NIIN IS 7H, 4320, 015028206, PUMP,CENTRIFUGAL, 999-4213-E-13. The Contract Officer would like to exercise a 100% option quantity within 365-days of the effective date of the repair contract award. The contractor will provide the same delivery time, and will indicate option quantity price. A modification will be completed at the time the option is exercised and all current contract terms and conditions will apply to the option quantity. IMPORTANT NOTE: This RFQ is for repair. Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor will provide the price reduction amount per unit per month the contractor does not meet the RTAT up to a maximum dollar amount. The Government does not own the data or the rights to the data needed to purchase / contract repair of this part from additional sources. It has been determined to be uneconomical to buy the data or rights to the data. It is uneconomical to reverse engineer the part.Interested parties may obtain copies of Military and Federal Specifications and Standards, Qualified Products Lists (QPLs), Qualified Product Databases (QPDs), Military Handbooks, and other standardized documents from the DoD Single Stock Point (DODSSP) at Document Automation and Production Service (DAPS) in Philadelphia, PA. NOTE: Patterns, Drawings, Deviation Lists, Purchase Descriptions, etc. are NOT stocked at DODSSP. Most documents are available in Adobe PDF format from ASSIST-Online at: http://quicksearch.dla.mil/. Users may use ASSIST-Quick Search to search for and download available documents directly using standard browser software. Documents that are not available for downloading from ASSIST-Quick Search can be ordered from the DODSSP website using the ASSIST Shopping Wizard after obtaining a DODSSP Customer Account by following the registration procedures. Users who do not have access to the internet may contact the DODSSP ASSIST Help Desk at 215-697-6396 (DSN: 442-6396), or mail their request to DLA Document Services, Bldg. 4/D, 700 Robbins Avenue, Philadelphia PA 19111-5094. The proposed contract action is for supplies or services for which the Government intends to solicit and negotiate with only one source under the authority of FAR 6.302-1. All responsible sources may identify their interest and capability to respond to the requirement or submit proposals, quotations or capability statements. This notice of intent is not a request for competitive proposals. A determination by the Government not to compete with this proposed contract based upon responses to this notice is solely within the discretion of the Government. Information received will normally be considered solely for the purpose of determining whether to conduct a competitive procurement.Award will be made only if the offeror, the product/service, or the manufacturer meets the qualification requirement(s) at time of award, in accordance with FAR clause 52.209-1. The solicitation identifies the office where additional information can be obtained concerning qualification requirements and is cited in each individual solicitation.Based upon market research, the Government is not using the policies contained in FAR Part 12, Acquisition of Commercial Items, in its solicitation for the described supplies or services. However, interested persons may identify to the contracting officer their interest and capability to satisfy the Government's requirement with a commercial item within 15 days of this notice.