Inactive

1. Offerors are hereby notified that this Amendment is issued to extend the closing date and time for receipt of proposals under Solicitation SPE601-21-R-0303 TO: 23 June 2021 at 1:00 PM Central Dayli... 1. Offerors are hereby notified that this Amendment is issued to extend the closing date and time for receipt of proposals under Solicitation SPE601-21-R-0303 TO: 23 June 2021 at 1:00 PM Central Daylight Time (CDT) for the following locations and soliciatation line numbers: a. Buckley AFB, CO, (Sol# 0108, 0116-0119) b. Peterson AFB, CO, (Sol# 0079, 0083-0086) c. Great Falls, MT, (Sol# 0003, 0016-0019) d. Wyoming ANG, WY (Sol# 0114, 0138-0141) e. Scott AFB, IL (Sol# 0106, 0111, 0128-0130) f. Peoria ANG, IL (Sol# 0049, 0054-0057) 2. Clarification of Government requirements should be requested by the Offeror by submitting questions and/or comments not later than 21 June 2021 by 1:00 PM CDT, to the Contracting Officer, Tammie Campbell via email at: Tammie.Campbell@dla.mil . 3. The following 52.212-4 Contract Terms and Conditions-Commercial Items (Oct 2018) clause is hereby amended: (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. Shall also include any accident, explosion, governmental law, ordinance, rule or regulation, whether valid or invalid, extraordinary failure of equipment or apparatus, inability to obtain electricity or other type of energy, feedstock, raw or finished material from normal sources of supply, labor, equipment or transportation, or any similar or different contingency beyond its reasonable control which would prevent or delay performance or make performance commercially impracticable whether or not the contingency is of the same class as those enumerated above, it being expressly agreed that such enumeration is non-exclusive. In the event any such contingency affects only a part of Contractor's capability to produce and/or deliver Product, Contractor will allocate production and/or deliveries among the requirements of all its affected customers and Contractor's own requirements in a fair and reasonable manner. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (h) Patent indemnity. Deleted. (o) Warranty. The items delivered hereunder will meet the specifications outlined in MIL-PRF-27210J and Commercial Item Description (CID) A-A595003D. The Government may reject any item which does not meet the specifications and no charge will be made for the item so rejected. No claim of any kind with respect to the conformance of items to the foregoing specifications, whether or not based on negligence, warranty, strict liability or any other theory of law, will be greater than the price of the quantity of nonconforming item(s) in respect to which such claim is made. The foregoing constitutes the Government’s exclusive remedy and the Contractor’s sole obligation with respect to any such claim. The Contractor does not make any other express warranty regarding products delivered under this contract. In relation to all other items or services delivered hereunder the Contractor confirms they will meet the specifications under the terms of this contract. (p) Limitation of liability.The Contractor will not be liable to the Government for any incidental, consequential, indirect, special or exemplary damages (including lost profits, sales, loss of business, economic loss, production or other similar damages) arising in connection with this contract without regard to the nature of the claim or the underlying theory or cause of action (whether in contract, tort, strict liability, equity or any other theory of law) on which such damages are based. The Contractor does not assume any responsibility for the suitability and the results of using the items alone or in combination with other articles or substances and in any manufacturing, medical, or other process or procedures. 4. Potential offerors shall sign the SF-30 amendment (block 15a-c) and acknowledge the solicitation/amendment(s)and submit with their prospective submitted proposals if applicable, not later than 23 June 2021 by 1:00 PM CDT, to the Contracting Officer, Tammie Campbell via email at: Tammie.Campbell@dla.mil. EMAIL SUBJECT LINE: Midwest Region 9.1C, Solicitation SPE601-21-R-0303, Amendment 0004 5. Except as provided in this Amendment, all other provisions and terms of Solicitation SPE601-21-R-0303 remain unchanged.

Inactive

The Defense Logistics Agency Energy (DLA Energy), as the Department of Defense (DOD) Integrated Material Manager (IMM) for Aerospace Energy products and related services has a five (5) year requiremen... The Defense Logistics Agency Energy (DLA Energy), as the Department of Defense (DOD) Integrated Material Manager (IMM) for Aerospace Energy products and related services has a five (5) year requirement for delivery of Aviator's Breathing Oxygen (ABO) NSN 6830-01-644-2463, IAW MIL PRF -272105 7 August 2013; Nitrogen, Technical (LN2) Type II, Grade B, NSN 6830-01-644-2557 IAW CID A-A 59503C dated 3 Mar 2011, delivered f.o.b. Destination into Contractor-owned tanks and Government-owned tanks at the following Midwest locations: Locations Product Type Estimated 5 Year Quantity Cannon AFB, NM ABO 96,000 NAS JRB Ft Worth, TX ABO 150,000 NAS JRB Ft Worth, TX LN2 90,000 Montana ANG, MT ABO 50,000 Randolph AFB, TX ABO 240,000 Sioux City ANG, IA ABO 66,000 Tinker AFB, OK (76TH) LN2 498,000 Tinker AFB, OK ABO ABO 378,000 Lackland AFB, TX (149TH) ABO 30,000 Tulsa ANG, OK ABO 60,000 Altus AFB, OK ABO 168,000 Peoria ANG, IL ABO 31,500 Whiteman AFB, MO ABO 42,000 Ellington ANG, TX ABO 60,000 Holloman AFB, NM ABO 210,000 Kirtland AFB, NM ABO 42,000 Laughlin AFB, TX ABO 81,000 Peterson AFB, CO ABO 60,000 Dyess AFB, TX ABO 90,000 Scott AFB, IL ABO 51,000 Sioux Falls ANG, SD ABO 75,000 Vance AFB, OK ABO 270,000 Lackland AFB, TX (433RD) ABO 150,000 Lackland AFB, TX (433RD) LN2 420,000 Buckley AFB, CO ABO 60,000 Little Rock AFB, AR ABO 150,000 Minot AFB, ND ABO 240,000 Sheppard AFB, TX ABO 600,000 St. Joseph ANG, MO ABO 75,000 Wyoming ANG, WY ABO 55,000 St. Paul ANG, MN ABO 34,000 Offutt AFB, NE ABO 48,000 (Alternate Delivery Site: Lincoln, NE) Period of Performance: 1 May 2021 – 31 Aug 2022 (16 Months) Offutt AFB, NE ABO 132,000 Period of Performance: 1 Sep 2022 – 30 Apr 2026 (44 Months) The requirement also includes Non-Recurring Services of Emergency/Emergency Delivery, Detention Fee, Fill Line Restriction Orifice, Tank Hot Fill, Tank Usage Fee, Installation of Equipment and Removal of Equipment. The period of performance is for 1 May 2021 – 30 April 2026. The anticipated Award Date is 1 April 2021. The Government may choose to award multiple Firm Fixed Price, Requirements type contracts using Federal Acquisition Regulation (FAR) Part 12, Commercial Acquisition procedures. Offerors are required to have the capability to support bulk shipments. Award will be made to the offeror(s) determined to be the Best Value to the Government, price and other factors considered, using the Lowest Price, Technically Acceptable Source Selection Process. Subject solicitation will be issued on or about 1 February 2021 and will be posted on the website https://beta.sam.gov. It is the responsibility of interested vendors to monitor the beta.sam.gov website for amendments that may be issued to this solicitation. For changes made after the closing date, only those offerors that provide a proposal by the closing date will be provided any changes/amendments and considered for future discussions and/or award. All responsible sources may submit a proposal, which will be considered by the agency. All potential offerors should contact the Contracting Officer identified above for additional information and/or to communicate concerns. Site Visit Requests In accordance with DLA Contract Text L-0004 L54.02 Site Visit (AEROSPACE ENERGY) (DLA ENERGY APR 2006) (a) It is the responsibility of the offerors to inspect the site where supplies are to be delivered and/or services are to be performed and to obtain all available information about the site necessary to satisfy themselves about general and local conditions that may affect delivery as well as cost of contract performance, to the extent that the information is reasonably obtainable. Offerors are responsible for any costs incurred for any site inspection and for obtaining information. (b) In no event shall failure to inspect the site constitute grounds for a claim after contract award. (c) Offerors who are interested in a site inspection should not contact the customer(s) directly, but forward such request(s), in writing, directly to the DLA Contracting Officer for this procurement. Site visits are not required, but are highly recommended. Due to numerous locations being procured under Midwest Region 9.1C requirement, vendors interested in conducting sites visits shall complete and submit Attachment B – Site Visit Request form to the Contracting Officer, Tammie D. Campbell via email: tammie.campbell@dla.mil no later than 2 February 2021, 10:00 A.M. Central Time (CT). Email Subject Line shall include: Site Visit Request, Midwest Region 9.1C, Solicitation SPE601-21-R-0303. At a minimum attendees will be required to provide proof of identity to access military installations, wear a face mask, wear closed toed shoes and practice social distancing to the maximum extent practicable. For questions regarding Small Business or Small Disadvantage Business affairs contact the DLA Small Business Office at 571-767-0192.